UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
WASHINGTON, D.C. 20549
FORM 10-K
(Mark One)
x ANNUAL REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
For the fiscal year ended December 31, 2015
OR
o TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
For the transition period from to
Commission file number: 001-34145
Primoris Services Corporation
(Exact name of registrant as specified in its charter)
Delaware |
|
20-4743916 |
(State or other jurisdiction of |
|
(I.R.S. Employer |
incorporation or organization) |
|
Identification No.) |
2100 McKinney Avenue, Suite 1500 |
|
75201 |
(Address of principal executive offices) |
|
(Zip Code) |
(214) 740-5600
(Registrants telephone number, including area code)
Securities registered pursuant to Section 12(b) of the Act:
Title of each class |
|
Name of exchange on which registered |
Common Stock, $0.0001 par value |
|
The NASDAQ Stock Market LLC |
Securities registered pursuant to Section 12(g) of the Act: None
Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act. Yes x No o
Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or Section 15(d) of the Act. Yes o No x
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes x Noo
Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§ 229.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files). Yes x No o
Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K is not contained herein, and will not be contained, to the best of registrants knowledge, in definitive proxy or information statements incorporated by reference in Part III in this Form 10-K or any amendment to this Form 10-K. o
Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company (as defined in Rule 12b-2 of the Exchange Act).
Large accelerated filer x |
|
Accelerated filer o |
|
|
|
Non-accelerated filer o |
|
Smaller Reporting Company o |
Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes o Nox
The aggregate market value of the voting common equity held by non-affiliates of the registrant was approximately $794.7 million based upon the closing price of such common equity as of June 30, 2015 (the last business day of the Registrants most recently completed second fiscal quarter). On February 29, 2016, there were 51,752,201 shares of common stock, par value $0.0001, outstanding. For purposes of this Annual Report on Form 10-K, in addition to those stockholders which fall within the definition of affiliates under Rule 405 of the Securities Act of 1933, holders of ten percent or more of the Registrants common stock are deemed to be affiliates.
FORWARD-LOOKING STATEMENTS
This Annual Report on Form 10-K contains forward-looking statements within the meaning of Section 27A of the Securities Act of 1933, as amended (the Securities Act), and Section 21E of the Securities Exchange Act of 1934, as amended (the Exchange Act), which are subject to the safe harbor created by those sections. Forward-looking statements include information concerning our possible or assumed future results of operations, business strategies, financing plans, competitive position, industry environment, potential growth opportunities, the effects of regulation and the economy, generally. Forward-looking statements include all statements that are not historical facts and usually can be identified by terms such as anticipates, believes, could, estimates, expects, intends, may, plans, potential, predicts, projects, should, will, would or similar expressions.
Forward-looking statements involve known and unknown risks, uncertainties and other factors which may cause our actual results, performance or achievements to be materially different from any future results, performance or achievements expressed or implied by the forward-looking statements. We discuss many of these risks in detail in Item 1A. Risk Factors. You should read this Annual Report on Form 10-K completely and with the understanding that our actual future results may be materially different from what we expect.
Given these uncertainties, you should not place undue reliance on forward-looking statements. Forward-looking statements represent our managements beliefs and assumptions only as of the date of this Annual Report on Form 10-K. We assume no obligation to update forward-looking statements publicly, or to update the reasons actual results could differ materially from those anticipated in any forward-looking statements, even if new information becomes available.
Business Overview
Primoris Services Corporation (Primoris, the Company, we, us, or our) is a holding company of various subsidiaries which form one of the larger publicly traded specialty contractors and infrastructure companies in the United States. Serving diverse end-markets, we provide a wide range of construction, fabrication, maintenance, replacement, water and wastewater, and engineering services to major public utilities, petrochemical companies, energy companies, municipalities, state departments of transportation and other customers. We install, replace, repair and rehabilitate natural gas, refined product, water and wastewater pipeline systems; large diameter gas and liquid pipeline facilities; and heavy civil projects, earthwork and site development. We also construct mechanical facilities and other structures, including power plants, petrochemical facilities, refineries, water and wastewater treatment facilities and parking structures. Finally, we provide specialized process and product engineering services.
Historically, we have longstanding relationships with major utility, refining, petrochemical, power and engineering companies. We have completed major underground and industrial projects for a number of large natural gas transmission and petrochemical companies in the western United States, as well as significant projects for our engineering customers. We enter into a large number of contracts each year and the projects can vary in length from several weeks to as long as 48 months for completion on larger projects. Although we have not been dependent upon any one customer, in any year a small number of customers tend to constitute a substantial portion of our total revenues.
The Companys common stock trades on the NASDAQ Select Global Market under the symbol PRIM. Founded as ARB, Inc. (ARB) in 1960, we became organized as Primoris in Nevada in 2003, and we became a Delaware public company in July 2008 when we merged with a special purpose acquisition company (a non-operating shell company).
Our service capabilities and geographic footprint have expanded primarily through the following four significant acquisitions over the last six years.
In 2009, we acquired James Construction Group, LLC, a privately-held Florida limited liability company (JCG). Headquartered in Baton Rouge, Louisiana, JCG is one of the largest general contractors based in the Gulf Coast states and is engaged in highway, industrial and environmental construction, primarily in Louisiana, Texas, Mississippi and Florida. JCG and its predecessor company have been in business for over 80 years.
In 2010, we acquired Rockford Corporation (Rockford). Rockford specializes in construction of large diameter natural gas and liquid pipeline projects and related facilities throughout the United States.
In 2012, we purchased Sprint Pipeline Services, L.P. (Sprint), a Texas based company headquartered near Houston, which we renamed as Primoris Pipeline Services (PPS) in March 2015. PPS provides a comprehensive range of pipeline construction, maintenance, upgrade, fabrication and specialty services primarily in the southeastern United States.
In November 2012, we purchased Q3 Contracting, Inc., a privately-held Minnesota corporation (Q3C). Based in Little Canada, Minnesota (north of St. Paul), Q3C specializes in small diameter pipeline and gas distribution construction, restoration and other services, primarily in the upper Midwest region of the United States.
In addition to these primary acquisitions, we have entered into several agreements to purchase smaller businesses or business assets to start a business as we continue to seek opportunities to expand our skill sets or operating locations. These include The Saxon Group (Saxon) and The Silva Group (Silva) (merged with JCG) which we acquired in 2012. During 2014 we acquired Vadnais Trenchless Services, Inc. (Vadnais) and made three small acquisitions during the third quarter, consisting of the purchase of the net assets of Surber Roustabout, LLC (Surber), Ram-Fab, LLC (Ram-Fab) and Williams Testing, LLC (Williams). In February 2015, we acquired the net assets of Aevenia, Inc. We continue to evaluate potential acquisition candidates especially those with strong management teams with good reputations.
Reportable Segments
The Company segregates its business into three operating segments: the West Construction Services segment (West segment), the East Construction Services segment (East segment) and the Energy segment (Energy segment).
The West segment includes the underground and industrial operations and construction services performed by ARB, ARB Structures, Inc., Rockford, Q3C, and Vadnais. ARB and ARB Structures perform work primarily in California; while, Rockford operates throughout the United States and Q3C operates in Colorado and the upper Midwest United States. The segment also includes three joint venture operations. The West segment consists of business headquartered primarily in the Western United States.
The East segment includes the JCG Heavy Civil division, JCG Infrastructure and Maintenance division, BW Primoris and Cardinal Contractors, Inc. construction businesses, located primarily in the Southeastern United States and the Gulf Coast region of the United States.
The Energy segment includes the operations of the Primoris Energy Services (PES) pipeline and gas facility construction and maintenance operations and the PES Industrial division, whose operations are located primarily in the southeastern United States and in the Gulf Coast region. This segment also includes the Primoris Aevenia,Inc. (Aevenia), Surber and Ram-Fab operations and the OnQuest, Inc. and OnQuest Canada, ULC operations, which provide for the design and installation of liquid natural gas (LNG) facilities and high-performance furnaces and heaters for the oil refining, petrochemical and power generation industries.
Each of the three segments specializes in a range of services that include designing, building/installing, replacing, repairing/rehabilitating and providing management services for construction related projects. Our services include:
· Providing installation of underground pipeline, cable and conduits for entities in the petroleum, petrochemical and water industries;
· Providing maintenance services to utilities for installation and repair of gas distribution lines;
· Providing installation and maintenance of industrial facilities for entities in the petroleum, petrochemical and water industries;
· Providing installation of commercial and industrial cast-in-place structures;
· Providing construction of highways and bridges; and
· Providing industrial and environmental construction.
Trends
We continue to operate in an uncertain business environment with increasing regulatory requirements and a significant decrease in the price of commodities, including oil and gas pricing, during the last 18 months. While by many indicators the United States economy has recovered from the recessionary levels of the past few years, capital expenditure levels by many of our customers have remained at lower levels. Economic and regulatory issues have adversely affected our customers and have affected demand for our services. For some of our customers, the additional uncertainty associated with state and federal budgets adds to the difficulty in predicting the timing or magnitude that industry trends may have on our business, particularly in the near-term.
The direct impact of the reduction in oil and gas prices is found in three of our end markets: upstream, midstream and downstream. The lower commodity prices have reduced to a minimum the capital expenditure budgets of oil and gas producers which have reduced or eliminated most work in the oil and gas shale formations. This has reduced the demand for our upstream pipeline services such as opportunities in oil and gas gathering lines, compressor systems and related infrastructure especially in the shale formations. While the longer term opportunities for midstream customers remain, as the existing pipeline infrastructure appears to be insufficient to meet the potential natural gas demand, in the near term capital expenditure is expected to fall. However, the lower natural gas prices may provide midstream opportunities to build large diameter pipelines for gas utility customers. Finally for downstream refineries, low prices tend to lead to more maintenance and outage work as plants are operated at higher levels; however, the low oil prices may result in delays and deferral for some of the maintenance work.
The gas utility industry continues to outsource an increasing amount of its infrastructure construction, maintenance and inspection services. Large rate regulated utilities in many states continue to rely more on outside contractors, rather than their own employees, to provide many of the services needed to maintain and expand their utility plants. This trend provides opportunity for our West segment operations.
The U.S. Energy Information Administration has stated that the number of natural gas-fired power plants built will increase significantly over the next two decades. While renewable energy generation continues to increase and become a larger percentage of the overall power generation mix, natural gas facilities, especially the conversion of current facilities to more efficient sources of power, may provide a significant contribution to the revenue and profitability of the West segment and over the next few years also the Energy segment. Regulations limiting the discharge of cooling water into the ocean will require construction of alternative cooling systems and may lead to repowering at current sites over the next few years in California.
As many states institute renewable power standards mandating renewable energy generation as a part of the total power usage, large, utility-scale projects will provide construction opportunities over the next few years. In many locations, the development
and construction of solar and wind facilities may result in a need for traditional plants to meet demand when the renewable resources are not available. In addition, alternative energy sources such as waste-to-power facilities provide long-term construction opportunities. The low long-term natural gas prices and the increased emission regulations of the Environmental Protection Agency may result in the construction of gas-fired power plants as an alternative to coal-fired plants. We believe that our gas-fired plant experience and industry knowledge will provide opportunities for us.
The continuing long-term low cost of natural gas is leading to industrial opportunities, as chemical plants that use natural gas as a feedstock initiate new projects or expand current facilities. Construction for many of these projects is expected in the Louisiana and Texas Gulf Coast region, which requires significant site preparation work as part of the project. Both our East and Energy segments provide services to many of the companies planning facility additions.
The low price and abundance of natural gas may lead to the development and construction of LNG export facilities, since natural gas prices in many international markets are greater than those in the United States. Future export LNG facilities could also provide opportunity for construction of additional pipelines. In addition, the development of small scale LNG facilities could provide opportunity for both our East and Energy segments.
At the end of 2015, opportunities for our highway construction services improved. The federal government enacted a four-year highway funding program, and the voters in the state of Texas adopted Proposition 7 to increase highway funding. In the United States, highway funding increased in 2015 compared to 2014. Our highway construction operation is focused on the states of Louisiana, Texas and Mississippi. Of these states, Texas continues to increase its highway construction budget, while the other two states have cut back funding in the past several years.
Over the past few years, several areas of the United States have suffered significant drought-like conditions. In these areas, state and municipal officials are considering using alternative sources for potable water, including using water pipelines to transport water from distant aquifers or building complex water treatment facilities to treat non-potable water. In some areas such as West Texas, state agencies are contemplating significant investment to improve the quantity of water. These investments may provide an opportunity for our East segment services. However, the planning cycle for major water and wastewater projects to address the drought tends to move very slowly, and opportunities may take several years to come to fruition.
Strategy
Our strategy continues to emphasize the following key elements:
· Diversification Through Controlled Expansion. We continue to emphasize the expansion of our scope of services beyond our current focus by increasing the scope of services offered to current customers and by adding new customers. We will evaluate acquisitions that offer growth opportunities and the ability to leverage our resources as a leading service provider to the oil and gas, power, refining and water industries. Our strategy also considers selective expansion to new geographic regions.
· Emphasis on Retention of Existing Customers and Recurring Revenue. In order to fully leverage our relationships with our existing customer base, we believe it is important to maintain strong customer relationships and to expand our base of recurring revenue sources and recurring customers.
· Ownership of Equipment. Many of our services are equipment intensive. The cost of construction equipment, and in some cases the availability of construction equipment, provides a significant barrier to entry into several of our businesses. We believe that our ownership of a large and varied construction fleet and our maintenance facilities enhances our access to reliable equipment at a favorable cost.
· Stable Work Force. Our business model emphasizes self-performance of a significant portion of our work. In each of our separate segments, we maintain a stable work force of skilled, experienced laborers, many of whom are cross-trained in projects such as pipeline and facility construction, refinery maintenance, and piping systems.
· Selective Bidding. We selectively bid on projects that we believe offer an opportunity to meet our profitability objectives or that offer the opportunity to enter promising new markets. In addition, we review our bidding opportunities to attempt to minimize concentration of work with any one customer, in any one industry, or in stressed labor markets. We believe that by carefully positioning ourselves in market segments that have meaningful barriers of entry, we can position ourselves so that we compete with other strong, experienced bidders.
· Maintain a conservative capital structure and strong balance sheet. We have maintained a capital structure that provides access to debt financing as needed while relying on tangible net worth to provide the primary support for our operations. We believe this structure provides both our customers and banks and bonding companies assurance of our financial
capabilities. We maintain a revolving credit facility to provide letter of credit capability; however, we have not had any outstanding bank borrowing against this facility while we have been a public company.
Backlog
Backlog is discussed in Item 7. Managements Discussion and Analysis of Financial Condition and Results of Operations of this Annual Report on Form 10-K.
Customers
We have longstanding customer relationships with major utility, refining, petrochemical, power and engineering companies. We have completed major underground and industrial projects for a number of large natural gas transmission and petrochemical companies in the western United States, as well as significant projects for our engineering customers. Through JCG, we expanded our customer base to include a significant presence in the Gulf Coast region of the United States; with Q3C, we expanded into the upper Midwest United States; and with Rockford, we are expanding throughout the United States. The various acquisitions have also changed the composition of our customer base with significant increases in state agency projects. We enter into a large number of contracts each year and the projects can vary in length from several weeks, to as long as 48 months for completion on larger projects. Although we have not been dependent upon any one customer in any year, a small number of customers tend to constitute a substantial portion of our total revenues.
Our customers have included many of the leading energy and utility companies in the United States, including, among others, Enterprise Liquids Pipeline, Xcel Energy, Pacific Gas & Electric, Southern California Gas, Sempra Energy, Williams, NRG, Chevron, Calpine, and Kinder Morgan.
The following customers accounted for more than 5% of our revenues in the periods indicated:
Description of customers business |
|
2015 |
|
2014 |
|
2013 |
|
Texas DOT |
|
9.5 |
% |
8.8 |
% |
7.2 |
% |
Private gas and electric utility |
|
9.0 |
% |
7.0 |
% |
5.4 |
% |
Chemical/energy producer |
|
9.0 |
% |
* |
|
* |
|
Pipeline operator |
|
8.6 |
% |
* |
|
* |
|
Gas utility |
|
6.6 |
% |
* |
|
7.4 |
% |
Public gas and electric utility |
|
6.2 |
% |
6.9 |
% |
7.9 |
% |
Petrochemical producer |
|
* |
|
7.9 |
% |
* |
|
Pipeline operator |
|
* |
|
5.8 |
% |
* |
|
Gas utility |
|
* |
|
* |
|
7.7 |
% |
Totals |
|
48.9 |
% |
36.4 |
% |
35.6 |
% |
(*) Indicates a customer with less than 5% of revenues during such period.
As can be seen from the table, the customers accounting for revenues in excess of 5% each year varies from year to year due to the nature of our business. A large construction project for a customer may result in significant revenues in that one year, with significantly less revenues in subsequent years after project completion.
For the years ended December 31, 2015, 2014 and 2013, 59.4%, 53.6% and 50.0%, respectively, of total revenues were generated from the top ten customers of the Company in each year. In each of the years, a different group of customers comprised the top ten customers by revenue.
Management at each of our business units is responsible for developing and maintaining successful long-term relationships with customers. Our business unit management teams build existing customer relationships to secure additional projects and increase revenue from our current customer base. Business unit managers are also responsible for pursuing growth opportunities with prospective new customers.
We believe that our strategic relationships with customers will result in future opportunities. Some of our strategic relationships are in the form of strategic alliance or long-term maintenance agreements. However, we realize that future opportunities also require cost effective bids, as pricing is a key element for most construction projects.
Ongoing Projects
The following is a summary of significant ongoing construction projects demonstrating our capabilities in different markets at December 31, 2015:
Segment |
|
Project |
|
Location |
|
Approximate |
|
Estimated |
|
Remaining |
| ||
|
|
|
|
|
|
(Millions) |
|
|
|
(Millions) |
| ||
West |
|
500 MW Natural Gas Simple Cycle Power Plant |
|
Carlsbad, CA |
|
$ |
212 |
|
11/2017 |
|
$ |
209 |
|
West |
|
125 Mile Natrual Gas Pipeline |
|
Central Florida |
|
$ |
209 |
|
09/2017 |
|
$ |
207 |
|
East |
|
I-49 Parkway |
|
Broussard, LA |
|
$ |
58 |
|
05/2017 |
|
$ |
38 |
|
East |
|
Bell IH-35 LP 363 To Troy |
|
Troy, TX |
|
$ |
128 |
|
10/2017 |
|
$ |
73 |
|
Energy |
|
Methane Reformer Construction |
|
Beaumont, TX |
|
$ |
27 |
|
09/2017 |
|
$ |
19 |
|
East & Energy |
|
Industrial facility |
|
Lake Charles, LA |
|
$ |
290 |
|
06/2016 |
|
$ |
115 |
|
Competition
We face substantial competition on large construction projects from both regional and national contractors. Competitors on small construction projects range from a few large construction companies to a variety of smaller contractors. We compete with many local and regional firms for construction services and with a number of large firms on select projects. Each business segment faces varied competition depending on the types of project and services offered.
We compete with different companies in different end markets. Large competitors in our underground markets include Quanta Services, Inc. and MasTec Inc.; competitors in our industrial end markets include Kiewit Corporation; and competitors in our highway services include Sterling Construction Company, and privately-held Boh Brothers and Zachary Construction Company. In each market we may also compete with local, private companies.
We believe that the primary factors influencing competition in our industry are price, reputation for quality, delivery and safety, relevant experience, availability of skilled labor, machinery and equipment, financial strength, knowledge of local markets and conditions, and estimating abilities. We believe that we compete favorably in all of these factors.
Geographic Areas Financial Information
The majority of the Companys revenues are derived from customers in the United States with approximately 1% generated from sources outside the United States. Assets located outside the United States also represent approximately 1% of total assets of the Company. Our revenue from operations in the United States is related to projects primarily in the geographic United States. Our revenue from operations in Canada is primarily derived from our Energy segments office in Calgary, Canada, but relates to specific projects in other countries, such as in the Far East and Australia.
Risks Attendant to Foreign Operations
In 2015 less than 1% of our revenue was attributable to external customers in foreign countries. The current expectation is that a similar portion of revenue will continue to come from international projects for the foreseeable future. Though a small portion of our revenues, international operations are subject to foreign economic and political uncertainties and risks as disclosed more fully in Item 1A Risk Factors of this Annual Report. Unexpected and adverse changes in the foreign countries in which we operate could result in project disruptions, increased costs and potential losses. Our business is subject to fluctuations in demand and to changing domestic and international economic and political conditions which are beyond our control.
Contract Provisions and Subcontracting
We typically structure contracts as unit-price, time and material, fixed-price or cost plus fixed fee. A substantial portion of our revenue is derived from contracts that are fixed price or fixed unit price contracts. While the fixed unit price contract shifts the risk of estimating the quantity of units required for a particular project to the party retaining us, any increase in our unit cost over the unit price bid, whether due to inflation, inefficiency, faulty estimates or other factors, is borne by us. Under a fixed price contract, we undertake to provide labor, equipment and services required by a project for a competitively bid or negotiated fixed price. The materials required under a fixed price contract, such as pipe, turbines, boilers and vessels are often supplied by the party retaining us.
Under a fixed unit price contract, we are committed to providing materials or services required by a project at fixed unit prices. Both cost and quantity risks related to time and material and cost plus fixed fee contracts are generally shifted to the party retaining us.
Construction contracts are primarily obtained through competitive bidding or through negotiations with long-standing customers. We are typically invited to bid on projects undertaken by recurring customers who maintain pre-qualified contractor lists. Contractors are selected for the pre-approved contractor lists by virtue of their prior performance for such customers, as well as their experience, reputation for quality, safety record, financial strength and bonding capacity.
In evaluating bid opportunities, we consider such factors as the customer, the geographic location of the work, the availability of labor, our competitive advantage or disadvantage relative to other likely contractors, our current and projected workload, the likelihood of additional work, and the projects cost and profitability estimates. We use computer-based estimating systems and our estimating staff has significant experience in the construction industry. The project estimates form the basis of a project budget against which performance is tracked through a project cost system; thereby enabling management to monitor a project. Project costs are accumulated and monitored regularly against billings and payments to assure proper control of cash flow on the project.
Most contracts provide for termination of the contract for the convenience of the owner. In addition, many contracts are subject to certain completion schedule requirements with liquidated damages in the event schedules are not met. To date, these provisions have not materially adversely affected us.
We act as prime contractor on a majority of the construction projects we undertake. In the construction industry, the prime contractor is normally responsible for the performance of the entire contract, including subcontract work. Thus, we are potentially subject to increased costs and reputational risk associated with the failure of one or more subcontractors to perform as anticipated. While we subcontract specialized activities such as blasting, hazardous waste removal and electrical work, we perform most of the work on our projects with our own resources, including labor and equipment.
Our gas distribution services are typically provided pursuant to renewable contracts on a unit-cost basis. Fees on unit-cost contracts are negotiated and are earned based on units completed. Historically, substantially all of the gas distribution customers have renewed their maintenance contracts. Facilities maintenance services, such as regularly scheduled and emergency repair work, are provided on an ongoing basis at predetermined rates.
Risk Management, Insurance and Bonding
We maintain general liability and excess liability insurance, covering our construction equipment, and workers compensation insurance, in amounts consistent with industry practices. In the States of California, Texas and Louisiana, we self-insure our workers compensation claims in an amount of up to $250,000 per occurrence, and we maintain insurance covering larger claims. In addition, we maintain umbrella coverage policies. We believe that our insurance programs are adequate.
We maintain a diligent safety and risk management program that has resulted in a favorable loss experience factor. Through our safety director and the employment of a large staff of regional and site specific safety managers, we have been able to effectively assess and control potential losses and liabilities in both the pre-construction and performance phases of our projects. Though we strongly focus on safety in the workplace, we cannot give assurances that we can prevent or reduce all injuries or claims in our workplace.
In connection with our business, we generally are required to provide various types of surety bonds guaranteeing our performance under certain public and private sector contracts. Our ability to obtain surety bonds depends upon our capitalization, working capital, backlog, past performance, management expertise and other factors and the surety companys current underwriting standards. To date, we have obtained the level of surety bonds necessary for the needs of our business.
Regulation
Our operations are subject to various federal, state, local and international laws and regulations including:
· Licensing, permitting and inspection requirements;
· Regulations relating to worker safety, including those established by the Occupational Safety and Health Administration;
· Permitting and inspection requirements applicable to construction projects; and
· Contractor licensing requirements.
We believe that we have all the licenses required to conduct our operations and that we are in substantial compliance with applicable regulatory requirements.
Environmental Matters and Climate Change Impacts
We are subject to numerous federal, state, local and international environmental laws and regulations governing our operations, including the handling, transportation and disposal of non-hazardous and hazardous substances and wastes, as well as emissions and discharges into the environment, including discharges to air, surface water, groundwater and soil. We also are subject to laws and regulations that impose liability and cleanup responsibility for releases of hazardous substances into the environment. Under some of these laws and regulations, liability can be imposed for cleanup of previously owned or operated properties, or properties to which hazardous substances or wastes were sent by current or former operations at our facilities, regardless of whether we directly caused the contamination or violated any law at the time of discharge or disposal. The presence of contamination from such substances or wastes could interfere with ongoing operations or adversely affect our ability to sell, lease or use our properties as collateral for financing.
In addition, we could be held liable for significant penalties and damages under certain environmental laws and regulations and also could be subject to a revocation of our licenses or permits, which could materially and adversely affect our business and results of operations. Our contracts with our customers may also impose liabilities on us regarding environmental issues that arise through the performance of our services. From time to time, we may incur costs and obligations for correcting environmental noncompliance matters and for remediation at or relating to certain of our properties. We believe that we are in substantial compliance with our environmental obligations to date and that any such obligations will not have a material adverse effect on our business or financial performance.
The potential physical impact of climate change on our operations is highly uncertain. Climate change may result in, among other things, changes in rainfall patterns, storm patterns and intensities and temperature levels. As discussed elsewhere in this Annual Report on Form 10-K, including in Item 1A. Risk Factors, our operating results are significantly influenced by weather. Therefore, major changes in historical weather patterns could significantly impact our future operating results. For example, if climate change results in significantly more adverse weather conditions in a given period, we could experience reduced productivity, which could negatively impact our revenues and gross margins.
Climate change could also affect our customers and the types of projects that they award. Demand for power projects, underground pipelines or highway projects could be affected by significant changes in weather. Reductions in project awards could adversely affect our operations and financial performance.
Employees
We believe that our employees are our most valuable resource in successfully completing construction work. Our ability to maintain sufficient continuous work for approximately 5,500 hourly employees helps us to instill in our employees loyalty to and understanding of our policies and contributes to our strong production, safety and quality record.
As of December 31, 2015, we employed 1,209 salaried employees and 5,802 hourly employees. The total number of hourly personnel employed is subject to the volume of construction in progress. During the calendar year 2015, the aggregate number of employees ranged from approximately 5,500 to 7,000.
The following is a summary of employees by function and location as of December 31, 2015:
|
|
CA |
|
LA |
|
TX |
|
CO |
|
FL |
|
MN |
|
Other |
|
Canada |
|
Total |
|
Salaried |
|
324 |
|
257 |
|
469 |
|
17 |
|
32 |
|
17 |
|
63 |
|
30 |
|
1,209 |
|
Hourly |
|
1,923 |
|
1,441 |
|
1,745 |
|
123 |
|
159 |
|
58 |
|
353 |
|
0 |
|
5,802 |
|
Total |
|
2,247 |
|
1,698 |
|
2,214 |
|
140 |
|
191 |
|
75 |
|
416 |
|
30 |
|
7,011 |
|
Several of our subsidiaries have operations that are unionized through the negotiation and execution of collective bargaining agreements. These collective bargaining agreements have varying terms and are subject to renegotiation upon expiration. We have not experienced recent work stoppages and believe our employee and union relations are good.
Website Access and Other Information
Our website address is www.prim.com. You may obtain free electronic copies of our Annual Reports on Form 10-K, Quarterly Reports on Form 10-Q, Current Reports on Form 8-K, and any amendments to these reports through our website under the Investors tab or through the website of the Securities and Exchange Commission (the SEC) at www.sec.gov. These reports are available on our website as soon as reasonably practicable after we electronically file them with, or furnish them to, the SEC. In addition, our Code of Ethics (including a separate supplement which applies to our CEO, CFO and senior financial executives) and the charters of our Audit Committee, Compensation Committee and Governance and Nominating Committee are posted on our website under the Investor Relations/Corporate Governance tab. We intend to disclose on our website any amendments or waivers to our Code of Ethics that are required to be disclosed pursuant to Item 5.05 of Form 8-K. You may obtain copies of these items from our website.
We will make available to any stockholder, without charge, copies of our Annual Report on Form 10-K as filed with the SEC. For copies of this or any other information, stockholders should submit a request in writing to Primoris Services Corporation, Inc., Attn: Corporate Secretary, 2100 McKinney Avenue, Suite 1500, Dallas, TX 75201.
This Annual Report on Form 10-K and our website may contain information provided by other sources that we believe are reliable. However, we cannot assure you that the information obtained from other sources is accurate or complete. No information on our website is incorporated by reference herein and should not be considered part of this Annual Report.
Our business is subject to a variety of risks and uncertainties, many of which are described below. However, the following list is not all-inclusive, and there can be no assurance that we have correctly identified and appropriately assessed all factors affecting our business or that the publicly available or other information with respect to these matters is complete and correct. Additional risks and uncertainties not presently known to us or that we currently believe to be immaterial also may have a material adverse effects on our business in the future. This Form 10-K includes projections, assumptions and beliefs that are intended to be forward looking statements and should be read in conjunction with the discussion of Forward Looking Statements at the beginning of this Annual Report on Form 10-K.
The following risk factors could have a material adverse effect our business, the results of our operations, our cash flow and the price of our shares. These risk factors could prevent us from meeting our goals or expectations.
Risks Related Primarily to Operating our Business
Our financial and operating results may vary significantly from quarter-to-quarter and year-to-year.
Our business is subject to seasonal and annual fluctuations. Some of the quarterly variation is the result of weather, particularly rain, ice and snow, which create difficult operating conditions. Similarly, demand for routine repair and maintenance services for gas utilities is lower during their peak customer needs in the winter. Some of the annual variation is the result of large construction projects which fluctuate based on general economic conditions and customer needs. Annual and quarterly results may also be adversely affected by:
· Changes in our mix of customers, projects, contracts and business;
· Regional or national and/or general economic conditions and demand for our services;
· Variations and changes in the margins of projects performed during any particular quarter;
· Increases in the costs to perform services caused by changing weather conditions;
· The termination or expiration of existing agreements or contracts;
· The budgetary spending patterns of customers;
· Increases in construction costs that we may be unable to pass through to our customers;
· Cost or schedule overruns on fixed-price contracts;
· Availability of qualified labor for specific projects;
· Changes in bonding requirements and bonding availability for existing and new agreements;
· The need and availability of letters of credit;
· Costs we incur to support growth whether organic or through acquisitions;
· The timing and volume of work under contract; and
· Losses experienced in our operations.
As a result, our operating results in any particular quarter may not be indicative of the operating results expected for any other quarter or for an entire year.
Demand for our services may decrease during economic recessions or volatile economic cycles, and a reduction in demand in end markets may adversely affect our business.
A substantial portion of our revenues and profits is generated from construction projects the awarding of which we do not directly control. The engineering and construction industry historically has experienced cyclical fluctuations in financial results due to economic recessions, downturns in business cycles of our customers, material shortages, price increases by subcontractors, interest rate fluctuations and other economic factors beyond our control. When the general level of economic activity deteriorates, our customers may delay or cancel upgrades, expansions, and/or maintenance and repairs to their systems. Many factors, including the financial condition of the industry, could adversely affect our customers and their willingness to fund capital expenditures in the future.
Economic, regulatory and market conditions affecting our specific end markets may adversely impact the demand for our services, resulting in the delay, reduction or cancellation of certain projects and these conditions may continue to adversely affect us in the future.
Much of the work that we perform in the highway markets involves funding by federal, state and local governments. While the federal funding and funding in some states appear to be stabilizing or improving, in other locations, funding for these projects could remain at very low levels.
We are also dependent on the amount of work our customers outsource. In a slower economy, our customers may decide to outsource less infrastructure services reducing demand for our services. In addition, consolidation, competition or capital constraints in the industries we serve may result in reduced spending by our customers.
Industry trends and government regulations could reduce demand for our pipeline construction services.
The demand for our pipeline construction services is dependent on the level of capital project spending by companies in the oil and gas industry. This level of spending is subject to large fluctuations depending primarily on the current and expectations of future prices of oil and natural gas. The price is a function of many factors, including levels of supply and demand, government policies and regulations, oil industry refining capacity and the potential development of alternative fuels. Since the middle of 2014, there has been a significant decrease in oil prices. These lower prices have resulted in the reduction or elimination of activity in the discovery or development of oil and gas reserves as customers curtail their capital spending on underground projects which has resulted in a reduction of demand for our services.
Specific government decisions could affect demand for our construction services. For example, a limitation on the use of fracking technology, or creation of significant regulatory issues for the construction of underground pipelines, could significantly reduce our underground work.
Many of our customers are regulated by federal and state government agencies and the addition of new regulations or changes to existing regulations may adversely impact demand for our services and the profitability of those services.
Many of our energy customers are regulated by FERC, and our utility customers are regulated by state public utility commissions. These agencies could change the way in which they interpret current regulations and may impose additional regulations. These changes could have an adverse effect on our customers and the profitability of the services they provide which could reduce demand for our services.
Our business may be materially adversely impacted by regional, national and/or global requirements to significantly limit or reduce greenhouse gas emissions in the future.
Greenhouse gases that result from human activities, including burning of fossil fuels, are the focus of increased scientific and political scrutiny and may be subjected to various legal requirements. International agreements, federal laws, state laws and various regulatory schemes limit or otherwise regulate emissions of greenhouse gases, and additional restrictions are under consideration by different governmental entities. We derive a significant amount of revenues and contract profits from engineering and construction services to clients that own and/or operate a wide range of process plants and own and/or operate electric power generating plants that generate electricity from burning natural gas or various types of solid fuels. These plants may emit greenhouse gases as part of the process to generate electricity or other products. Compliance with the existing greenhouse gas regulation may prove costly or difficult. It is possible that owners and operators of existing or future process plants and electric generating plants could be subject to new or changed environmental regulations that result in significantly limiting or reducing the amounts of greenhouse gas emissions, increasing the cost of emitting such gases or requiring emissions allowances. The costs of controlling such emissions or obtaining
required emissions allowances could be significant. It also is possible that necessary controls or allowances may not be available. Such regulations could negatively impact client investments in capital projects in our markets, which could negatively impact the market for our products and/or services. This could materially adversely affect our business.
In addition, the establishment of rules limiting greenhouse gas emissions could impact our ability to perform construction services or to perform these services with current levels of profitability. New regulations may require us to acquire different equipment or change processes. The new equipment may not be available, or it may not be purchased or rented in a cost effective manner. Project deferrals, delays or cancellations resulting from the potential regulations could adversely impact our business.
Changes to renewable portfolio standards and decreased demand for renewable energy projects could negatively impact our future results of operations, cash flows and liquidity.
A significant portion of our future business may be focused on providing construction and/or installation services to owners and operators of solar power and other renewable energy facilities. Currently, the development of solar and other renewable energy facilities is highly dependent on tax credits, the existence of renewable portfolio standards and other state incentives. Renewable portfolio standards are state-specific statutory provisions requiring that electric utilities generate a certain amount of electricity from renewable energy sources. These standards have initiated significant growth in the renewable energy industry and a potential demand for renewable energy infrastructure construction services. Since renewable energy is generally more expensive to produce, elimination of, or changes to, existing renewable portfolio standards, tax credits or similar environmental policies may negatively affect future demand for our services.
We may lose business to competitors through the competitive bidding processes.
We are engaged in highly competitive businesses in which most customer contracts are awarded through bidding processes based on price and the acceptance of certain risks. We compete with other general and specialty contractors, both foreign and domestic, including large international contractors and small local contractors. The strong competition in our markets requires maintaining skilled personnel and investing in technology, and it also puts pressure on profit margins. We do not obtain contracts from all of our bids and our inability to win bids at acceptable profit margins would adversely affect our business.
We may be unsuccessful at generating internal growth which may affect our ability to expand our operations or grow our business.
Our ability to generate internal growth may be affected by, among other factors, our ability to:
· Attract new customers;
· Increase the number of projects performed for existing customers;
· Hire and retain qualified personnel;
· Successfully bid for new projects; and
· Adapt the range of services we offer to address our customers evolving construction needs.
In addition, our customers may reduce the number or size of projects available to us due to their inability to obtain capital. Our customers may also reduce projects in response to economic conditions.
Many of the factors affecting our ability to generate internal growth may be beyond our control, and we cannot be certain that our strategies will be successful or that we will be able to generate cash flow sufficient to fund our operations and to support internal growth. If we are unsuccessful, we may not be able to achieve internal growth, expand our operations or grow our business.
The timing of new contracts may result in unpredictable fluctuations in our business.
Substantial portions of our revenues are derived from project-based work that is awarded through a competitive bid process. The portion of revenue generated from the competitive bid process for 2015, 2014 and 2013 was approximately 47%, 64%, and 66%, respectively. It is generally very difficult to predict the timing and geographic distribution of the projects that we will be awarded. The selection of, timing of or failure to obtain projects, delays in award of projects, the re-bidding or termination of projects due to budget overruns, cancellations of projects or delays in completion of contracts could result in the under-utilization of our assets and reduce our cash flows. Even if we are awarded contracts, we face additional risks that could affect whether, or when, work will begin. For example, some of our contracts are subject to financing, permitting and other contingencies that may delay or result in termination of projects. We may have difficulty in matching workforce size and equipment location with contract needs. In some cases, we may be required to bear the cost of a ready workforce and equipment that is larger than necessary, resulting in unpredictability in our cash flow, expenses and profitability. If any expected contract award or the related work release is delayed or not received, we could incur
substantial costs without receipt of any corresponding revenues. Moreover, construction projects for which our services are contracted may require significant expenditures by us prior to receipt of relevant payments by a customer and may expose us to potential credit risk if the customer encounters financial difficulties. Finally, the winding down or completion of work on significant projects will reduce our revenue and earnings if these projects have not been replaced in the current period.
We derive a significant portion of our revenues from a few customers, and the loss of one or more of these customers could have significant effects on our revenues, resulting in adverse effects on our financial condition, results of operations and cash flows.
Our customer base is highly concentrated, with our top ten customers accounting for approximately 59% of our revenue in 2015, 53% of our revenue in 2014 and 50% of our revenue in 2013. However, the customers included in our top ten customer list generally varies from year to year. Our revenue is dependent both on performance of larger construction projects and relatively smaller Master Services Agreements (MSA) contracts. For the large construction projects, the completion of the project does not represent the permanent loss of a customer.
We also generate ongoing revenues from our MSA customers, generally regulated gas utilities. If we were to lose one of these customers, our revenue could significantly decline. Reduced demand for our services by larger construction customers or a loss of a significant MSA customer could have an adverse effect on our business.
Our international operations expose us to legal, political and economic risks in different countries as well as currency exchange rate fluctuations that could harm our business and financial results. We could be adversely affected by our failure to comply with laws applicable to our foreign activities, such as the U.S. Foreign Corrupt Practices Act.
During 2015, 2014 and 2013, revenue attributable to our services outside of the United States was 0.9%, 1.0% and 0.8% of our total revenue, respectively. While much of this revenue is derived from the operations of our Canadian subsidiary, OnQuest Canada, ULC, actual activities have occurred in several far eastern countries and in Australia. There are risks inherent in doing business internationally, including:
· Imposition of governmental controls and changes in laws, regulations, policies, practices, tariffs and taxes;
· Political and economic instability;
· Changes in United States and other national government trade policies affecting the market for our services;
· Potential non-compliance with a wide variety of laws and regulations, including the United States Foreign Corrupt Practices Act (FCPA) and similar non-United States laws and regulations;
· Currency exchange rate fluctuations, devaluations and other conversion restrictions;
· Restrictions on repatriating foreign profits back to the United States; and
· Difficulties in staffing and managing international operations.
The FCPA and similar anti-bribery laws in other jurisdictions prohibit U.S.-based companies and their intermediaries from making improper payments to non-U.S. officials for the purpose of obtaining or retaining business. We pursue opportunities in certain parts of the world that experience government corruption, and in certain circumstances, compliance with anti-bribery laws may conflict with local customs and practices. Our internal policies mandate compliance with all applicable anti-bribery laws. We require our partners, subcontractors, agents and others who work for us or on our behalf to comply with the FCPA and other anti-bribery laws. There is no assurance that our policies or procedures will protect us against liability under the FCPA or other laws for actions taken by our agents, employees and intermediaries. If we are found to be liable for FCPA violations (either due to our own acts or our inadvertence, or due to the acts or inadvertence of others), we could suffer from severe criminal or civil penalties or other sanctions, which could have a material adverse effect on our reputation and business. In addition, detecting, investigating and resolving actual or alleged FCPA violations is expensive and could consume significant time and attention of our senior management.
Backlog may not be realized or may not result in revenues or profits.
Backlog is measured and defined differently by companies within our industry. We refer to backlog as our estimated revenue on uncompleted contracts, including the amount of revenue on contracts on which work has not begun, less the revenue we have recognized under such contracts plus an estimated level of MSA revenues for the next four quarters. Backlog is not a comprehensive indicator of future revenues. Most contracts may be terminated by our customers on short notice. Reductions in backlog due to cancellation by a customer, or for other reasons, could significantly reduce the revenue that we actually receive from contracts in backlog. In the event of a project cancellation, we may be reimbursed for certain costs, but we typically have no contractual right to the total revenues reflected in our backlog. Projects may remain in backlog for extended periods of time. While backlog includes estimated MSA revenues, customers are not contractually obligated to purchase an amount of services under the MSA.
Given these factors, our backlog at any point in time may not accurately represent the revenue that we expect to realize during any period, and our backlog as of the end of a fiscal year may not be indicative of the revenue we expect to earn in the following fiscal year. Inability to realize revenue from our backlog could have an adverse effect our business.
Backlog is an indicator of future revenues; however, recognition of revenues from backlog does not necessarily ensure that the projects will be profitable. Poor project or contract performance could impact profits from contracts included in backlog.
Our actual cost may be greater than expected in performing our fixed-price and unit-price contracts, causing us to realize significantly lower profits or losses on our projects.
We currently generate, and expect to continue to generate, a portion of our revenue and profits under fixed-price and unit-price contracts. The approximate portion of revenue generated from fixed-price contracts for the years 2015, 2014 and 2013 was 39%, 23% and 48%, respectively. The approximate portion of revenue generated from unit-price contracts for the years 2015, 2014 and 2013 was 43%, 32%, and 39%, respectively. In general, we must estimate the costs of completing a specific project to bid these types of contracts. The actual cost of labor and materials may vary from the costs we originally estimated, and we may not be successful in recouping additional costs from our customers. These variations, may cause gross profits for a project to differ from those we originally estimated. Reduced profitability or losses on projects could occur due to changes in a variety of factors such as:
· Failure to properly estimate costs of engineering, materials, equipment or labor;
· Unanticipated technical problems with the structures, materials or services being supplied by us, which may require that we spend our own money to remedy the problem;
· Project modifications not reimbursed by the client creating unanticipated costs;
· Changes in the costs of equipment, materials, labor or subcontractors;
· Our suppliers or subcontractors failure to perform;
· Changes in local laws and regulations, and;
· Delays caused by local weather conditions.
As projects grow in size and complexity, these factors may combine, and depending on the size of the particular project, variations from the estimated contract costs could have a material adverse effect on our business.
We require subcontractors and suppliers to assist us in providing certain services, and we may be unable to retain the necessary subcontractors or obtain supplies to complete certain projects adversely affecting our business.
We use subcontractors to perform portions of our contracts and to manage workflow, particularly for design, engineering, procurement and some foundation work. While we are not dependent on any single subcontractor, general market conditions may limit the availability of subcontractors to perform portions of our contracts causing delays and increases in our costs.
We also use suppliers to provide the materials and some equipment used for projects. If a supplier fails to provide supplies and equipment at a price we estimated, fails to provide supplies and equipment that are not of acceptable quantity or fails to provide supplies when scheduled, we may be required to source the supplies or equipment at a higher price or may be required to delay performance of the project. The additional cost or project delays could negatively impact project profitability.
Failure of a subcontractor or supplier to comply with laws, rules or regulations could negatively affect our reputation and our business.
We may enter into joint ventures which require satisfactory performance by our venture partners of their obligations. The failure of our joint venture partners to perform their joint venture obligations could impose additional financial and performance obligations on us that could result in reduced profits or losses for us with respect to the joint venture.
As is typical in our industry, we may enter into various joint ventures and teaming arrangements where control may be shared with unaffiliated third parties. At times, we also participate in joint ventures where we are not a controlling party. In such instances, we may have limited control over joint venture decisions and actions, including internal controls and financial reporting which may have an impact on our business. If our joint venture partners fail to satisfactorily perform their joint venture obligations, the joint venture may be unable to adequately perform or deliver its contracted services. Under these circumstances, we may be required to make additional investments or provide additional services to ensure the adequate performance and delivery of the contracted services. These additional obligations could result in reduced profits and may impact our reputation in the industry.
We may experience delays and defaults in client payments and we may pay our suppliers and subcontractors before receiving payment from our customers for the related services; we could experience an adverse effect on our financial condition, results of operations and cash flows.
We use subcontractors and material suppliers for portions of certain work, and our customers pay us for those related services. If we pay our suppliers and subcontractors for materials purchased and work performed for customers who fail to pay, or such customers delay in paying us for the related work or materials, we could experience a material adverse effect on our business.
Our inability to recover on claims against project owners or subcontractors for payment or performance could negatively affect our business.
We occasionally present claims or change orders to our clients and subcontractors for additional costs exceeding a contract price or for costs not included in the original contract price. If we do not properly document the nature of our claims and change orders, or are otherwise not successful in negotiating a reasonable settlement, we could incur reduced profitability or a loss on a project. Claims often occur from owner-caused delays or changes in scope from the original project. Claims may be subject to lengthy and costly arbitration or litigation and may require a lengthy process to resolve.
For some projects we may guarantee a timely completion or provide a performance guarantee which could result in additional costs to cover our obligations.
In our fixed-price contracts we may provide a project completion date, and in some of our projects we commit that the project will achieve specific performance standards. If we do not complete the project as scheduled, or if the project does not meet the contracted performance standards, we may be held responsible for the impact to the client resulting from the delay or the inability to meet the standards. Generally, the impact to the client is in the form of liquidated damages specified in the contract.
A significant portion of our business depends on our ability to provide surety bonds, and we may be unable to compete for or work on certain projects if we are not able to obtain the necessary surety bonds.
Our contracts frequently require that we provide payment and performance bonds to our customers. Under standard terms in the surety market, sureties issue or continue bonds on a project-by-project basis and can decline to issue bonds at any time or require the posting of additional collateral as a condition to issuing or renewing bonds.
Current or future market conditions, as well as changes in our surety providers assessments of our operating and financial risk, could cause our surety providers to decline to issue or renew, or to substantially reduce, the availability of bonds for our work and could increase our bonding costs. These actions could be taken on short notice. If our surety providers were to limit or eliminate our access to bonding, our alternatives would include seeking bonding capacity from other sureties, finding more business that does not require bonds and posting other forms of collateral for project performance, such as letters of credit or cash. We may be unable to secure these alternatives in a timely manner, on acceptable terms, or at all. Accordingly, if we were to experience an interruption or reduction in the availability of bonding capacity, we may be unable to compete for or work on certain projects.
Our bonding requirements may limit our ability to incur indebtedness, which would limit our ability to refinance our existing credit facilities or to execute our business plan.
Our ability to obtain surety bonds depends upon various factors including our capitalization, working capital, tangible net worth and amount of our indebtedness. In order to help ensure that we can obtain required bonds, we may be limited in our ability to incur additional indebtedness that may be needed to refinance our existing credit facilities upon maturity and to execute our business plan.
We may be unable to win some new contracts if we cannot provide clients with letters of credit.
For many of our clients, surety bonds provide an adequate form of security, but for some clients, additional security in the form of a letter of credit may be required. While we have capacity for letters of credit under our credit facility, the amount required by a client may be in excess of our credit limit. Any such amount would be issued at the sole discretion of our lenders. Failure to provide a letter of credit when required by a client may result in our inability to compete for or win a project.
During the ordinary course of our business, we may become subject to material lawsuits or indemnity claims.
We have in the past been, and may in the future be, named as a defendant in lawsuits, claims and other legal proceedings during the ordinary course of our business. These actions may seek, among other things, compensation for alleged personal injury, workers compensation, employment discrimination, breach of contract, property damage, punitive damages, and civil penalties or other losses or injunctive or declaratory relief. In addition, we generally indemnify our customers for claims related to the services we provide and actions we take under our contracts with them, and, in some instances, we may be allocated risk through our contract terms for actions by our customers or other third parties. Because our services in certain instances may be integral to the operation and performance of our customers infrastructure, we may become subject to lawsuits or claims for any failure of the systems on which we work, even if our services are not the cause of such failures, and we could be subject to civil and criminal liabilities to the extent that our services contributed to any property damage, personal injury or system failure. The outcome of any of these lawsuits, claims or legal proceedings could result in significant costs and diversion of managements attention to the business. Payments of significant amounts, even if reserved, could adversely affect our reputation and our business.
We are self-insured against potential liabilities.
Although we maintain insurance policies with respect to employers liability, general liability, auto and workers compensation claims, those policies are subject to deductibles or self-insured retention amounts of up to $250,000 per occurrence. We are primarily self-insured for all claims that do not exceed the amount of the applicable deductible/self-insured retention. In addition, for our employees not part of a collective bargaining agreement, we provide employee health care benefit plans. Our primary health insurance plan is subject to a deductible of $250,000 per individual claim per year.
Our insurance policies include various coverage requirements, including the requirement to give appropriate notice. If we fail to comply with these requirements, our coverage could be denied.
Losses under our insurance programs are accrued based upon our estimates of the ultimate liability for claims reported and an estimate of claims incurred but not reported. Insurance liabilities are difficult to assess and estimate due to unknown factors, including the severity of an injury, the extent of damage, the determination of our liability in proportion to other parties and the number of incidents not reported. The accruals are based upon known facts and historical trends.
Our business is labor intensive. If we are unable to attract and retain qualified managers and skilled employees, our operating costs may increase.
Our business is labor intensive and our ability to maintain our productivity and profitability may be limited by our ability to employ, train and retain skilled personnel necessary to meet our requirements. We may not be able to maintain an adequately skilled labor force necessary to operate efficiently and to support our growth strategy. We have from time-to-time experienced, and may in the future experience, shortages of certain types of qualified personnel. For example, periodically there are shortages of engineers, project managers, field supervisors, and other skilled workers capable of working on and supervising the construction of underground, heavy civil and industrial facilities, as well as providing engineering services. The supply of experienced engineers, project managers, field supervisors and other skilled workers may not be sufficient to meet current or expected demand. The beginning of new, large-scale infrastructure projects or increased competition for workers currently available to us, could affect our business, even if we are not awarded such projects. Labor shortages or increased labor costs could impair our ability to maintain our business or grow our revenues. If we are unable to hire employees with the requisite skills, we may also be forced to incur significant training expenses.
Our unionized workforce may commence work stoppages, which could adversely affect our operations.
As of December 31, 2015, approximately 24% of our hourly employees, primarily consisting of field laborers, were covered by collective bargaining agreements. Of the 82 collective bargaining agreements to which we are a party, 56 expire during 2016 and require renegotiation. Although the majority of these agreements prohibit strikes and work stoppages, we cannot be certain that strikes or work stoppages will not occur in the future. Strikes or work stoppages would adversely impact our relationships with our customers and could have an adverse effect on our business.
Our ability to complete future acquisitions could be adversely affected because of our union status for a variety of reasons. For instance, in certain geographic areas, our union agreements may be incompatible with the union agreements of a business we want to acquire and some businesses may not want to become affiliated with a union company. In addition, if we acquire a union affiliated company, we may increase our future exposure to withdrawal liabilities for any underfunded pension plans.
The current Federal administration has expressed strong support for legislation and regulation that would create more flexibility and opportunity for labor unions to organize non-union workers. This legislation or regulation could result in a greater percentage of our workforce being subject to collective bargaining agreements.
Withdrawal from multiemployer pension plans associated with our unionized workforce could adversely affect our financial condition and results of operations.
Our collective bargaining agreements generally require that we participate with other companies in multiemployer pension plans. To the extent those plans are underfunded, the Employee Retirement Income Security Act of 1974 (ERISA), as amended by the Multiemployer Pension Plan Amendments Act of 1980 (MEPA), may subject us to substantial liabilities under those plans if we withdraw from them or they are terminated. In addition, the Pension Protection Act of 2006 added new funding rules for multiemployer plans that are classified as endangered, seriously endangered or critical status. For a plan in critical status, additional required contributions and benefit reductions may apply if a plan is determined to be underfunded, which could adversely affect our financial condition or results of operations. For plans in critical status, we may be required to make additional contributions, generally in the form of surcharges on contributions otherwise required. Participation in those plans with high funding levels could adversely affect our results of operations, financial condition or cash flows if we are not able to adequately mitigate these costs.
The amount of the withdrawal liability legislated by ERISA and MEPA varies for every pension plan to which we contribute. For each plan, our liability is the total unfunded vested benefits of the plan multiplied by a fraction: the numerator of the fraction is the sum of our contributions to the plan for the past ten years and the denominator is the sum of all contributions made by all employers for the past ten years. For some pension plans to which we contribute, the unfunded vested benefits are in the billions of dollars. If we cannot reduce the liability through exemptions or negotiations, the withdrawal from a plan could have a material adverse impact on our business.
We depend on key personnel and we may not be able to operate and grow our business effectively if we lose the services of any of our key persons or are unable to attract qualified and skilled personnel in the future.
We are dependent upon the efforts of our key personnel, and our ability to retain them and hire other qualified employees. The loss of our executive officers or other key personnel could affect our ability to run our business effectively. Competition for senior management personnel is intense, and we may not be able to retain our personnel. The loss of any key person requires the remaining key personnel to divert immediate and substantial attention to seeking a replacement. In addition, as some of our key persons approach retirement age, we need to provide for smooth transitions. An inability to find a suitable replacement for any departing executive or senior officer on a timely basis could adversely affect our ability to operate and grow our business.
If we fail to integrate acquisitions successfully, we may experience operational challenges and risks which may have an adverse effect on our business.
As part of our growth strategy, we intend to acquire companies that expand, complement or diversify our business. Acquisitions may expose us to operational challenges and risks, including, among others:
· The diversion of managements attention from the day-to-day operations of the combined company;
· Managing a significantly larger company than before completion of an acquisition;
· The assimilation of new employees and the integration of business cultures;
· Retaining key personnel;
· The integration of information, accounting, finance, sales, billing, payroll and regulatory compliance systems;
· Challenges in keeping existing customers and obtaining new customers;
· Challenges in combining service offerings and sales and marketing activities;
· The assumption of unknown liabilities of the acquired business for which there are inadequate reserves;
· The potential impairment of acquired goodwill and intangible assets; and
· The inability to enforce covenants not to compete.
If we cannot effectively manage the integration process or if any significant business activities are interrupted as a result of the integration process of any acquisition, our business could suffer.
Our business growth could outpace the capability of our internal infrastructure and may prohibit us from expanding our operations or execute our business plan.
Our internal infrastructure may not be adequate to support our operations as they expand. To the extent that we are unable to buy or build equipment necessary for a project, either due to a lack of available funding or equipment shortages in the marketplace, we may be forced to rent equipment on a short-term basis or to find alternative ways to perform the work without the benefit of equipment ideally suited for the job, which could increase the costs of completing the project. We often bid for work knowing that we
will have to rent equipment on a short-term basis, and we include our assumptions of market equipment rental rates in our bid. If market rates for rental equipment increase between the time of bid submission and project execution, our margins for the project may be reduced. In addition, our equipment requires continuous maintenance, which we generally provide through our own repair facilities. If we are unable to continue to maintain the equipment in our fleet, we may be forced to obtain additional third-party repair services at a higher cost or be unable to bid on contracts.
Our business may be affected by difficult work sites and environments which may adversely affect our ability to procure materials and labor.
We perform our work under a variety of conditions, including, but not limited to, difficult and hard to reach terrain, difficult site conditions and busy urban centers where delivery of materials and availability of labor may be impacted. Performing work under these conditions can slow our progress, potentially causing us to incur contractual liability to our customers. These difficult conditions may also cause us to incur additional, unanticipated costs that we might not be able to pass on to our customers.
We may incur liabilities or suffer negative financial or reputational impacts relating to health and safety matters.
Our operations are subject to extensive laws and regulations relating to the maintenance of safe conditions in the workplace. While we have invested, and will continue to invest, substantial resources in our environmental, health and safety programs, our industry involves a high degree of operational risk and there can be no assurance that we will avoid significant liability exposure. Although we have taken what we believe are appropriate precautions, we have suffered fatalities in the past and may suffer additional fatalities in the future. Serious accidents, including fatalities, may subject us to substantial penalties, civil litigation or criminal prosecution. Claims for damages to persons, including claims for bodily injury or loss of life, could result in substantial costs and liabilities, which could materially and adversely affect our financial condition, results of operations or cash flows. In addition, if our safety record were to substantially deteriorate over time or we were to suffer substantial penalties or criminal prosecution for violation of health and safety regulations, our customers could cancel our contracts and not award us future business.
We may incur additional healthcare costs arising from federal healthcare reform legislation.
In March 2010, the Patient Protection and Affordable Care Act and the Health Care and Education Reconciliation Act of 2010 were signed into law in the U.S. This legislation expands health care coverage to many uninsured individuals and expands coverage to those already insured. The changes required by this legislation could cause us to incur additional healthcare and other costs for which we may not be reimbursed by our customers. The employee insurance requirements have begun to impact our expenses as the penalties for non-compliance by our employees continually increase. While we anticipate increases in our customer billing rates to reflect the increased expense, there can be no guarantee that we will be able to pass these costs to our customers or that our competition will increase their bids to reflect the increased healthcare costs. For our multi-year highway projects, we may not be able to anticipate further increases in healthcare costs associated with the healthcare reform legislation.
Interruptions in information technology or breaches in data security could adversely impact our operations, our ability to report financial results and our business.
We rely on computer, information and communication technology and related systems to operate our business. As we continue to grow our business, we need to add software and hardware and effectively upgrade our systems and network infrastructure in order to improve the efficiency and protection of our systems and information. Our computer and communications systems, and consequently our operations, could be damaged or interrupted by natural disasters, loss of power, telecommunications failures, acts of war, acts of terrorism, computer viruses, physical or electronic break-ins and actions by hackers and cyber-terrorists. Any of these, or similar, events could cause system disruptions, delays and loss of critical information, delays in processing transactions and delays in the reporting of financial information. While we have implemented network security and internal control measures, there can be no assurance that a system or network failure or data security breach would not adversely affect our business.
As a holding company, we are dependent on our subsidiaries for cash distributions to fund debt payments, dividend payments and other liabilities.
We are a holding company with no operations or significant assets other than the stock that we own of our subsidiaries.
We depend on dividends, loans and distributions from these subsidiaries to service our indebtedness, pay dividends, fund share repurchases and satisfy other financial obligations. If contractual limitations or legal regulations were to restrict the ability of our subsidiaries to make cash distributions to us, we may not have sufficient funds to cover our financial obligations.
We may need additional capital in the future for working capital, capital expenditures or acquisitions, and we may not be able to do so on favorable terms, or at all, which would impair our ability to operate our business or achieve our growth objectives.
Our ability to generate cash is essential for the funding of our operations and the servicing of our debt. If existing cash balances together with the borrowing capacity under our credit facilities were not sufficient to make future investments, make acquisitions or provide needed working capital, we may require financing from other sources. Our ability to obtain such additional financing in the future will depend on a number of factors including prevailing capital market conditions; conditions in our industry; and our operating results. These factors may affect our ability to arrange additional financing on terms that are acceptable to us. If additional funds were not available on acceptable terms, we may not be able to make future investments, take advantage of acquisitions or other opportunities or respond to competitive challenges.
Risks Related Primarily to the Financial Accounting of our Business
Our financial results are based upon estimates and assumptions that may differ from actual results.
In preparing our consolidated annual and quarterly financial statements in conformity with generally accepted accounting principles, many estimates and assumptions are used in determining the reported revenues and expenses recognized during the periods presented, and disclosures of contingent assets and liabilities known to exist as of the date of the financial statements. These estimates and assumptions must be made because certain information that is used in the preparation of our financial statements cannot be calculated with a high degree of precision from data available, is dependent on future events, or is not capable of being readily calculated based on generally accepted methodologies. Often times, these estimates are particularly difficult to determine, and we must exercise significant judgment. Estimates may be used in our assessments of the allowance for doubtful accounts, useful lives of property and equipment, fair value assumptions in analyzing goodwill and long-lived asset impairments, self-insured claims liabilities, revenue recognition under percentage-of-completion accounting and provisions for income taxes. Actual results for estimates could differ materially from the estimates and assumptions that we used.
Our use of percentage-of-completion accounting could result in a reduction or elimination of previously reported revenue and profits.
We recognize revenue using the percentage-of-completion method of accounting, using the cost-to-cost method, where revenues are estimated based on the percentage of costs incurred to date to total estimated costs. This method is used because management considers expended costs to be the best available measure of progress on these contracts. The earnings or losses recognized on individual contracts are based on estimates of total contract revenues, total expected costs and costs incurred to date. Contract losses are recognized in full when determined, and contract profit estimates are adjusted based upon ongoing reviews of contract profitability.
Penalties or potential charges are recorded when known or finalized, which generally is during the latter stages of the contract. In addition, we record adjustments to estimated costs of contracts when we believe the change in the estimate is probable and the amounts can be reasonably estimated. These adjustments could result in both increases and decreases in profit margins. Actual results could differ from estimated amounts and could result in a reduction or elimination of previously recognized earnings. In certain circumstances, it is possible that such adjustments could be significant and could have an adverse effect on our business.
Our reported results of operations and financial condition could be adversely affected as a result of changes in accounting standards.
In May 2014, the Financial Accounting Standards Board (FASB) finalized revised standards for revenue recognition which become effective for the Company beginning in 2018. In February 2016, the FASB issued a revised standard for accounting of operating leases, which becomes affective for the Company beginning in 2019. These changes and other future changes could result in changes in the way we report our financial results.
Our reported results of operations could be adversely affected as a result of impairments of goodwill, other intangible assets or investments.
When we acquire a business, we record an asset called goodwill for the excess amount we pay for the business over the net fair value of the tangible and intangible assets of the business we acquire. At December 31, 2015, our balance sheet included goodwill of $124 million and intangible assets of $36 million resulting from previous acquisitions. Fair value is determined using a combination of the discounted cash flow, market multiple and market capitalization valuation approaches. Under current accounting rules, goodwill and other intangible assets that have indefinite useful lives cannot be amortized, but instead must be tested at least annually for impairment, while intangible assets that have finite useful lives are amortized over their useful lives. Any impairment of the goodwill or intangible assets recorded in connection with the various acquisitions, or for any future acquisitions, would negatively impact our results of operations.
In addition, we may enter into various types of investment arrangements, such as an equity interest we hold in a business entity. Our equity method investments are carried at original cost and are included in other assets in our consolidated balance sheet and are adjusted for our proportionate share of the investees income, losses and distributions. Equity investments are reviewed for impairment by assessing whether any decline in the fair value of the investment below its carrying value is other than temporary. In making this determination, factors such as the ability to recover the carrying amount of the investment and the inability of the investee to sustain future earnings capacity are evaluated in determining whether an impairment should be recognized.
We may not be successful in continuing to meet the internal control requirements of the Sarbanes-Oxley Act of 2002.
The Sarbanes-Oxley Act of 2002 has many requirements applicable to us regarding corporate governance and financial reporting, including the requirements for management to report on internal controls over financial reporting and for our independent registered public accounting firm to express an opinion over the operating effectiveness of our internal control over financial reporting. At December 31, 2015, our internal control over financial reporting was effective using the internal control standards issued by the Committee of Sponsoring Organizations (COSO) of the Treadway Commission: Internal controlIntegrated Framework (1992). In 2013, an updated set of internal control standards, COSO 2013, was published. In October 2013, the Public Company Accounting Oversight Board issued Staff Audit Practice Alert 11, Considerations for Audits of Internal Control over Financial Reporting which addressed topics that should be considered by auditors in performing their audits of internal control. As a result, during 2015, we spent considerable time, effort and expense in making significant improvements in the documentation of the processes and procedures used in our controls over financial reporting. We also spent considerable effort in planning and testing a prudent migration to an integrated financial platform for a major part of our business. We expect to complete the migration to the new system in 2016. We believe that the efforts of 2015 will allow us to adopt the standards of COSO 2013 in 2016. Please note that there can be no assurance that our internal control over financial reporting will be effective in future years. Failure to maintain effective internal controls or the identification of material internal control deficiencies in acquisitions already made or made in the future could result in a decrease in the market value of our common stock, the reduced ability to obtain financing, the loss of customers, penalties and additional expenditures to meet the requirements in the future.
Starting in the fourth quarter of 2014 and continuing through the date of this Annual Report on Form 10-K, the Companys management, independent outside counsel and the Audit Committee of the Board of Directors have spent time and resources reviewing and analyzing various issues relating to the methods used by the Companys subsidiaries to recognize revenue and estimate contingencies for ongoing construction projects. The internal review remains in process, and we cannot estimate when the review will be completed. Since the start of the review, we have made process and procedural changes that we believe enhance our controls over revenue recognition.
As our internal review is ongoing, we cannot predict the final outcome of the review. Until our review efforts are completed, the Companys management, outside counsel and the Audit Committee of the Board of Directors will continue to devote time and resources to the review. A government entity or other third party could bring an action and seek injunctions, fines, civil and criminal penalties, or other remedies, or assert other claims or litigation against the Company with respect to any issues that might arise in connection with the review. We also may not be able to effectively improve and expand our financial infrastructure, and internal operating and administrative systems and controls, or do so on a timely basis. Findings from the our review could result in a loss of investor confidence and decrease in the market value of our common stock, the reduced ability to obtain financing and the loss of customers.
Risks Related to our Common Stock
Our common stock is subject to potential dilution to our stockholders.
As part of our acquisition strategy, we have issued shares of common stock and used shares of common stock as a part of contingent earn-out consideration, which have resulted in dilution to our stockholders. Our Articles of Incorporation permit us to issue up to 90 million shares of common stock of which 51.68 million were outstanding at December 31, 2015. While NASDAQ rules require that we obtain stockholder approval to issue more than 20% additional shares, stockholder approval is not required below that level. In addition, we can issue shares of preferred stock which could cause further dilution to the stockholder, resulting in reduced net income and cash flow available to common stockholders.
In 2013, our stockholders adopted our 2013 Equity Incentive Plan (Equity Plan). The Equity Plan replaced a previous plan. The Equity Plan authorized the Board of Directors to issue equity awards totaling 2,526,275 shares of our common stock. Our current director compensation plan, our management long-term incentive plan and any additional equity awards made will have the effect of diluting our earnings per share and stockholders percentage of ownership.
Our Chairman is a significant stockholder, which may make it possible for him to have significant influence over the outcome of matters submitted to our stockholders for approval and his interests may differ from the interests of other stockholders.
As of December 31, 2015 our Chairman of the Board beneficially owned approximately 20% of the outstanding shares of our common stock. He may have significant influence over the outcome of all matters submitted to our stockholders for approval, including the election of our directors and other corporate actions. Such influence could have the effect of discouraging others from attempting to purchase us or take us over and could reduce the market price offered for our common stock.
Delaware law and our charter documents may impede or discourage a takeover or change in control.
As a Delaware corporation, anti-takeover provisions may impose an impediment to the ability of others to acquire control of us, even if a change of control would be of benefit to our stockholders. In addition, certain provisions of our Articles of Incorporation and Bylaws also may impose an impediment or discourage others from a takeover. These provisions include:
· Our Board of Directors is classified;
· Stockholders may not act by written consent;
· There are restrictions on the ability of a stockholder to call a special meeting or nominate a director for election; and
· Our Board of Directors can authorize the issuance of preferred shares.
These types of provisions may limit the ability of stockholders to obtain a premium for their shares.
ITEM 1B. UNRESOLVED STAFF COMMENTS
None.
Facilities
Our executive offices are located at 2100 McKinney Avenue, Suite 1500, Dallas, Texas 75201. The telephone number of our executive office is (214) 740-5600. The East and Energy segments of our business have regional offices located in Baton Rouge, Louisiana; in Houston, Conroe, Fort Worth and Pasadena, Texas; Suwanee, Georgia and in Sarasota and Fort Lauderdale, Florida. The Energy segment also has business offices located in San Dimas, California and in Calgary, Canada. The West segment has regional offices located in Lake Forest, Pittsburg, San Francisco, Bakersfield and San Diego, California and offices located in Hillsboro, Oregon; Denver, Colorado; Montrose, Pennsylvania and Little Canada, Minnesota.
We lease most of the facilities used in our operations. The leases are generally for 10 to 12-year terms, expiring through 2023. The aggregate lease payments made for our facilities in 2015 were approximately $6.5 million. We believe that our facilities are adequate to meet our current and foreseeable requirements for the next several years.
We lease some of our facilities from Stockdale Investment Group, Inc. (SIGI). We believe that these leases were entered into on similar terms as would have been negotiated with an independent third party. Brian Pratt, our largest stockholder and our Chairman of the Board of Directors, holds a majority interest in SIGI and is the chairman and chief executive officer and a director of SIGI. John M. Perisich, our Executive Vice President and General Counsel, is secretary of SIGI.
Property, Plant and Equipment
We own and maintain both construction and transportation equipment. In 2015 we spent approximately $67.1 million in cash, in 2014 we spent approximately $88.0 million in cash and in 2013 we spent approximately $85.8 million in cash plus an additional $2.6 million through the use of capital leases. We estimate that our capital equipment includes the following:
· Heavy construction and specialized equipment3,287 units; and
· Transportation equipment5,199 units.
We believe the ownership of equipment is generally preferable to leasing to ensure the equipment is available as needed. In addition, ownership has historically resulted in lower overall equipment costs. We attempt to obtain projects that will keep our equipment fully utilized in order to increase profit. All equipment is subject to scheduled maintenance to insure reliability.
Maintenance facilities exist at most of our regional offices as well as on-site on major jobs to properly service and repair equipment. Major equipment not currently utilized is rented to third parties whenever possible to supplement equipment income.
The following summarizes total property, plant and equipment, net of accumulated depreciation, as of December 31, 2015 and 2014:
|
|
2015 |
|
2014 |
|
Useful Life |
| ||
|
|
(In Thousands) |
|
(In Thousands) |
|
|
| ||
Land and buildings |
|
$ |
56,248 |
|
$ |
40,604 |
|
30 years |
|
Leasehold improvements |
|
9,650 |
|
11,267 |
|
Lease life |
| ||
Office equipment |
|
5,958 |
|
3,651 |
|
3 - 5 years |
| ||
Construction equipment |
|
340,895 |
|
308,915 |
|
3 - 7 years |
| ||
Transportation equipment |
|
93,613 |
|
83,845 |
|
3 - 18 years |
| ||
|
|
506,364 |
|
448,282 |
|
|
| ||
Less: accumulated depreciation and amortization |
|
(222,819 |
) |
(176,851 |
) |
|
| ||
Net property, plant and equipment |
|
$ |
283,545 |
|
$ |
271,431 |
|
|
|
Legal Proceedings
On February 7, 2012, the Company was sued in an action entitled North Texas Tollway Authority (NTTA), Plaintiff v. James Construction Group, LLC, and KBR, Inc., Defendants, v. Reinforced Earth Company, Third-Party Defendant (the Lawsuit). The Company participated in court-ordered mediation for 18 months, and on February 25, 2015 the Lawsuit was settled for an expected cost to the Company of $9 million which was the accrued liability balance at December 31, 2014. As part of the settlement, one of the defendants paid us $8 million to remove all of their liability. Additionally, a second defendant agreed to provide up to $5.4 million to pay for the total expected remediation cost of approximately $22.4 million. The Company will use the $17 million to pay for a third-party contractor approved by the NTTA. In the event that the total remediation costs exceed the estimated amount, the second defendant would pay 20% of the excess amount and the Company would pay for 80% of the excess amount. The Company believes that the $17 million is the best and most probable estimate for its portion of the remediation cost as of December 31, 2015; however, the Company cannot provide assurance that the final cost will not exceed the amount accrued.
At December 31, 2015, the Company is engaged in dispute resolution to enforce collection for two construction projects completed by the Company in 2014. For one project, a cost reimbursable contract, the Company has recorded a receivable of $32.9 million, and for the other project, the Company has a receivable balance due of $17.9 million. At December 31, 2015, the Company has not recorded revenues in excess of cost for these two projects; however, the Company has specific reserves for both projects of approximately $26 million included in billings in excess of costs and estimated earnings. At this time, the Company cannot predict the amount that it will collect nor the timing of any collection. The dispute resolution for the $32.9 million receivable involves mandatory international arbitration for four separate construction projects. As part of the process of exchanging information with the owner, the Company determined in the fourth quarter of 2015 that there were no remaining claims from the owner for two of the smaller projects for which the Company had been paid in full. As a result, the Company recorded approximately $2 million in revenues and margin in the quarter.
The Company is subject to other claims and legal proceedings arising out of its business. The Company provides for costs related to contingencies when a loss from such claims is probable and the amount is reasonably determinable. In determining whether it is possible to provide an estimate of loss, or range of possible loss, the Company reviews and evaluates its litigation and regulatory matters on a quarterly basis in light of potentially relevant factual and legal developments. If we determine an unfavorable outcome is not probable or reasonably estimable, we do not accrue for a potential litigation loss. Management is unable to ascertain the ultimate outcome of other claims and legal proceedings; however, after review and consultation with counsel and taking into consideration relevant insurance coverage and related deductibles/self-insurance retention, management believes that it has meritorious defense to the claims and believes that the reasonably possible outcome of such claims will not, individually or in the aggregate, have a materially adverse effect on the consolidated results of operations, financial condition or cash flows of the Company.
Government Regulations
Our operations are subject to compliance with regulatory requirements of federal, state, and municipal agencies and authorities, including regulations concerning labor relations, affirmative action and the protection of the environment. While
compliance with applicable regulatory requirements has not adversely affected operations in the past, there can be no assurance that these requirements will not change and that compliance with such requirements will not adversely affect operations.
ITEM 4. MINE SAFETY DISCLOSURES
Not applicable.
ITEM 5. MARKET FOR REGISTRANTS COMMON EQUITY, RELATED STOCKHOLDER MATTERS AND ISSUER PURCHASES OF EQUITY SECURITIES
Market Information
On July 31, 2008, our common stock began trading on the NASDAQ Global Market under the symbol PRIM. Previously, our common stock traded on the OTC Bulletin Board under the ticker symbol RPSD. Prior to their expiration on October 2, 2010, the Company had certain warrants and unit purchase options outstanding that were traded under the NASDAQ Global Market under the symbols PRIMW and PRIMU, respectively.
We had outstanding 51,676,140 shares of common stock and 399 stockholders of record as of December 31, 2015. These stockholders of record include depositories that hold shares of stock for brokerage firms, which in turn, hold shares of stock for numerous beneficial owners.
The following table shows the range of market prices of our common stock during 2015 and 2014.
|
|
Market price per |
| ||||
|
|
High |
|
Low |
| ||
Year ended December 31, 2015 |
|
|
|
|
| ||
First quarter |
|
$ |
22.98 |
|
$ |
16.75 |
|
Second quarter |
|
$ |
20.00 |
|
$ |
17.07 |
|
Third quarter |
|
$ |
19.75 |
|
$ |
16.26 |
|
Fourth quarter |
|
$ |
23.79 |
|
$ |
17.17 |
|
|
|
|
|
|
| ||
Year ended December 31, 2014 |
|
|
|
|
| ||
First quarter |
|
$ |
33.35 |
|
$ |
29.26 |
|
Second quarter |
|
$ |
30.88 |
|
$ |
26.39 |
|
Third quarter |
|
$ |
29.80 |
|
$ |
23.88 |
|
Fourth quarter |
|
$ |
28.72 |
|
$ |
19.99 |
|
Dividends
The following table shows cash dividends to our common stockholders declared by the Company during the two years ended December 31, 2015:
Declaration Date |
|
Payable Date |
|
Record Date |
|
Type |
| |
February 26, 2014 |
|
April 15, 2014 |
|
March 31, 2014 |
|
$ |
0.035 per share |
|
May 2, 2014 |
|
July 15, 2014 |
|
June 30, 2014 |
|
$ |
0.035 per share |
|
August 5, 2014 |
|
October 15, 2014 |
|
September 30, 2014 |
|
$ |
0.040 per share |
|
November 4, 2014 |
|
January 15, 2015 |
|
December 31, 2014 |
|
$ |
0.040 per share |
|
|
|
|
|
|
|
|
| |
February 24, 2015 |
|
April 15, 2015 |
|
March 31, 2015 |
|
$ |
0.040 per share |
|
May 1, 2015 |
|
July 15, 2015 |
|
June 30, 2015 |
|
$ |
0.055 per share |
|
August 4, 2015 |
|
October 15, 2015 |
|
September 30, 2015 |
|
$ |
0.055 per share |
|
November 3, 2015 |
|
January 15, 2016 |
|
December 31, 2015 |
|
$ |
0.055 per share |
|
In addition, on February 22, 2015, the Board of Directors declared a $0.055 per common share dividend with a record date of March 31, 2016 and a payable date of on or about April 15, 2016. The payment of future dividends is contingent upon our revenues and earnings, capital requirements and general financial condition of the Company, as well as contractual restrictions and other considerations deemed relevant by the Board of Directors.
Equity Compensation Plan Information
In July 2008, the shareholders approved and the Company adopted the Primoris Services Corporation 2008 Long-term Incentive Equity Plan, which was replaced by the Primoris Services Corporation 2013 Long-term Incentive Equity Plan (2013 Equity Plan), as approved by the shareholders and adopted by the Company on May 3, 2013.
In March 2015, our employees purchased 96,828 shares of stock as part of a management incentive compensation program. As part of the quarterly compensation of the non-employee members of the Board of Directors, the Company issued 8,168 shares of common stock in March 2015 and 9,748 shares in August 2015. The issuance of the employee shares and the director shares were under the terms of the 2013 Equity Plan.
The following table gives information about our common stock that may be issued upon the exercise of options, warrants and rights under all of our existing equity compensation plans as of December 31, 2015.
Plan category |
|
Number of securities |
|
Weighted-average |
|
Number of securities |
|
Equity compensation plans approved by security holders |
|
148,512 |
|
0 |
|
2,163,907 |
|
Equity compensation plans not approved by security holders |
|
0 |
|
0 |
|
0 |
|
Total |
|
148,512 |
|
0 |
|
2,163,907 |
|
These securities represent shares of common stock available for issuance under our 2013 Equity Plan. The 2013 Equity Plan is discussed in Note 2 to our consolidated financial statements for the year ended December 31, 2015 included in Part II, Item 8 Financial Statements and Supplementary Data.
Repurchases of Securities
In February 2014, the Companys Board of Directors authorized a share repurchase program under which the Company, from time to time and depending on market conditions, share price and other factors, could acquire shares of its common stock on the open market or in privately negotiated transactions up to an aggregate purchase price of $23 million. During the period from February 2014 through September 2014, the Company purchased and cancelled 100,000 shares of stock for $2.8 million at an average cost of $28.44 per share. This share repurchase program expired on December 31, 2014, and there were no share repurchases authorized during 2015.
Sales of Unregistered Securities
The Company did not issue any unregistered shares of our common stock during 2014 or 2015.
Performance Graph
The following Performance Graph and related information shall not be deemed to be filed with the Securities and Exchange Commission, nor shall such information be incorporated by reference into any future filing under the Securities Act of 1933 or Securities Exchange Act of 1934, each as amended, except to the extent that we specifically incorporate it by reference into such filing.
The following graph compares the cumulative total return to holders of the Companys common stock during the five-year period from December 31, 2010, and in each quarter up through December 31, 2015. The return is compared to the cumulative total return during the same period achieved on the Standard & Poors 500 Stock Index (the S&P 500) and a peer group index selected by our management that includes five public companies within our industry (the Peer Group). The Peer Group is composed of MasTec, Inc., Matrix Service Company, Quanta Services, Inc., Sterling Construction Company, Inc. and Willbros Group, Inc. The companies in the Peer Group were selected because they comprise a broad group of publicly held corporations, each of which has some operations similar to ours. When taken as a whole, management believes the Peer Group more closely resembles our total business than any individual company in the group.
The returns are calculated assuming that an investment with a value of $100 was made in the Companys common stock and in each stock as of December 31, 2010. All dividends were reinvested in additional shares of common stock, although none of the comparable companies paid dividends during the periods shown. The Peer Group investment is calculated based on a weighted average of the five company share prices. The graph lines merely connect the measuring dates and do not reflect fluctuations between those dates. The stock performance shown on the graph is not intended to be indicative of future stock performance.
COMPARISON OF DECEMBER 31, 2010 THROUGH DECEMBER 31, 2015
CUMULATIVE TOTAL RETURN
Among Primoris Services Corporation (PRIM), the S&P 500 and the Peer Group
ITEM 6. SELECTED FINANCIAL DATA
The following selected financial data should be read in conjunction with Item 7, Managements Discussion and Analysis of Financial Condition and Results of Operations and our audited financial statements and the accompanying notes included elsewhere in this Annual Report on Form 10-K.
|
|
Year Ended December 31, |
| |||||||||||||
|
|
2015 |
|
2014 |
|
2013 |
|
2012 |
|
2011 |
| |||||
|
|
(In millions except share and per share data) |
| |||||||||||||
Statement of Operations Data: |
|
|
|
|
|
|
|
|
|
|
| |||||
Revenues |
|
$ |
1,929 |
|
$ |
2,086 |
|
$ |
1,944 |
|
$ |
1,542 |
|
$ |
1,460 |
|
Cost of revenues |
|
1,709 |
|
1,850 |
|
1,688 |
|
1,349 |
|
1,275 |
| |||||
Gross profit |
|
220 |
|
236 |
|
256 |
|
193 |
|
185 |
| |||||
Selling, general and administrative expense |
|
152 |
|
132 |
|
131 |
|
96 |
|
86 |
| |||||
Operating income |
|
68 |
|
104 |
|
125 |
|
97 |
|
99 |
| |||||
Other income (expense) |
|
(7 |
) |
(2 |
) |
(5 |
) |
(4 |
) |
(2 |
) | |||||
Income before provision for income taxes |
|
61 |
|
102 |
|
120 |
|
93 |
|
97 |
| |||||
Income tax provision |
|
(24 |
) |
(38 |
) |
(45 |
) |
(34 |
) |
(38 |
) | |||||
Net Income |
|
$ |
37 |
|
$ |
64 |
|
$ |
75 |
|
$ |
59 |
|
$ |
59 |
|
|
|
|
|
|
|
|
|
|
|
|
| |||||
Less net income attributable to noncontrolling interests |
|
|
|
(1 |
) |
(5 |
) |
(2 |
) |
|
| |||||
Net income attributable to Primoris |
|
$ |
37 |
|
$ |
63 |
|
$ |
70 |
|
$ |
57 |
|
$ |
59 |
|
|
|
|
|
|
|
|
|
|
|
|
| |||||
Dividends per common share |
|
$ |
0.205 |
|
$ |
0.15 |
|
$ |
0.135 |
|
$ |
0.12 |
|
$ |
0.11 |
|
|
|
|
|
|
|
|
|
|
|
|
| |||||
Earnings per share attributable to Primoris: |
|
|
|
|
|
|
|
|
|
|
| |||||
Basic |
|
$ |
0.71 |
|
$ |
1.22 |
|
$ |
1.35 |
|
$ |
1.10 |
|
$ |
1.15 |
|
Diluted |
|
$ |
0.71 |
|
$ |
1.22 |
|
$ |
1.35 |
|
$ |
1.10 |
|
$ |
1.14 |
|
|
|
|
|
|
|
|
|
|
|
|
| |||||
Weighted average common shares outstanding (in thousands): |
|
|
|
|
|
|
|
|
|
|
| |||||
Basic |
|
51,647 |
|
51,607 |
|
51,540 |
|
51,391 |
|
50,707 |
| |||||
Diluted |
|
51,798 |
|
51,747 |
|
51,610 |
|
51,406 |
|
51,153 |
|
|
|
As of December 31, |
| |||||||||||||
|
|
2015 |
|
2014 |
|
2013 |
|
2012 |
|
2011 |
| |||||
Balance Sheet Data: |
|
|
|
|
|
|
|
|
|
|
| |||||
Cash and cash equivalents |
|
$ |
161 |
|
$ |
139 |
|
$ |
196 |
|
$ |
158 |
|
$ |
120 |
|
Short term investments |
|
$ |
|
|
$ |
31 |
|
$ |
19 |
|
$ |
3 |
|
$ |
23 |
|
Accounts receivable, net |
|
$ |
321 |
|
$ |
337 |
|
$ |
305 |
|
$ |
268 |
|
$ |
187 |
|
Total assets |
|
$ |
1,132 |
|
$ |
1,111 |
|
$ |
1,051 |
|
$ |
931 |
|
$ |
728 |
|
Total current liabilities |
|
$ |
416 |
|
$ |
419 |
|
$ |
430 |
|
$ |
421 |
|
$ |
345 |
|
Long-term debt/capital leases, net of current portion |
|
$ |
233 |
|
$ |
205 |
|
$ |
193 |
|
$ |
132 |
|
$ |
67 |
|
Stockholders equity |
|
$ |
483 |
|
$ |
454 |
|
$ |
398 |
|
$ |
333 |
|
$ |
275 |
|
ITEM 7. MANAGEMENTS DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS
You should read the following discussion of our financial condition and results of operations in conjunction with the financial statements and the notes to those statements included as item 8 in this Annual Report on Form 10-K. This discussion includes forward-looking statements that are based on current expectations and are subject to uncertainties and unknown or changed circumstances. For a further discussion, please see Forward Looking Statements at the beginning of this Annual Report on Form 10-K. Our actual results may differ materially from those anticipated in these forward-looking statements as a result of many factors, including those risks inherent with our business as discussed in Item 1A Risk Factors.
The following discussion starts with an overview of our business and a discussion of trends, including seasonality, that affect our industry. That is followed by an overview of the critical accounting policies and estimates that we use to prepare our financial statements. Next we discuss our results of operations and liquidity and capital resources, including our off-balance sheet transactions and contractual obligations. We conclude with a discussion of our outlook and backlog.
Introduction
Primoris is a holding company of various subsidiaries, which form one of the larger publicly traded specialty contractors and infrastructure companies in the United States. Serving diverse end-markets, we provide a wide range of construction, fabrication, maintenance, replacement, water and wastewater, and engineering services to major public utilities, petrochemical companies, energy companies, municipalities, state departments of transportation and other customers. We install, replace, repair and rehabilitate natural gas, refined product, water and wastewater pipeline systems; large diameter gas and liquid pipeline facilities; and heavy civil projects, earthwork and site development. We also construct mechanical facilities and other structures, including power plants, petrochemical facilities, refineries, water and wastewater treatment facilities and parking structures. Finally, we provide specialized process and product engineering services.
We have longstanding customer relationships with major utility, refining, petrochemical, power and engineering companies. We have completed major underground and industrial projects for a number of large natural gas transmission and petrochemical
companies in the western United States, as well as significant projects for our engineering customers. We enter into a large number of contracts each year and the projects can vary in length from several weeks, to as long as 48 months for completion on larger projects. Although we have not been dependent upon any one customer in any year, a small number of customers tend to constitute a substantial portion of our total revenues.
We recognize revenues and profitability on our contracts depending on the type of contract. For our fixed price, or lump sum, contracts, we record revenue as the work progresses on a percentage-of-completion basis which means that we recognize revenue based on the percentage of costs incurred to date in proportion to the total estimated costs expected to complete the contract. Fixed price contracts may include retainage provisions under which customers withhold a percentage of the contract price until the project is complete. For our unit price, time and material, and cost-plus contracts, we recognize revenue as units are completed or services are performed. The Critical Accounting Policies and Estimates section below provides additional information on our contracts and revenue recognition practices.
The Company segregates its business into three operating segments, which include: The West Construction Services segment (West segment), the East Construction Services segment (East segment) and the Energy segment. The following is a brief description of each of our reportable segments and business activities.
The West segment includes the underground and industrial operations and construction services performed by ARB, Inc. (ARB), ARB Structures, Inc., Rockford Corporation (Rockford), Q3 Contracting, Inc. (Q3C), and Vadnais Trenchless Services, Inc. (Vadnais). ARB and ARB Structures perform work primarily in California; while, Rockford operates throughout the United States and Q3C operates in Colorado and the upper Midwest United States. The segment also included three joint venture operations. The West segment consists of business headquartered primarily in the western United States.
The East segment includes the James Construction Group (JCG) Heavy Civil division, the JCG Infrastructure and Maintenance division, BW Primoris, LLC and Cardinal Contractors, Inc. construction business, located primarily in the southeastern United States and in the Gulf Coast region of the United States and includes the heavy civil construction and infrastructure and maintenance operations.
The Energy segment businesses are located primarily in the southeastern United States and in the Gulf Coast region of the United States. The segment includes the operations of the Primoris Energy Services (PES) pipeline and gas facility construction and maintenance operations, the PES Industrial division, the Surber and Ram-Fab operations and the newly acquired Primoris Aevenia, Inc. (Aevenia) operations. Additionally, the segment includes the OnQuest, Inc. (OnQuest) and OnQuest Canada, ULC operations for the design and installation of high-performance furnaces and heaters for the oil refining, petrochemical and power generation industries.
The following table lists the Companys primary operating subsidiaries and their operating segment:
Subsidiary |
|
Operating Segment |
ARB |
|
West |
ARB Structures, Inc. |
|
West |
Q3C |
|
West |
Rockford |
|
West |
Vadnais |
|
West |
Silva Group (Silva) |
|
East |
Cardinal Contractors, Inc. |
|
East |
BW Primoris, LLC (BWP) |
|
East |
JCG |
|
|
JCG Heavy Civil Division |
|
East |
JCG Infrastructure and Maintenance Division |
|
East |
PES |
|
Energy |
PES Industrial Division (formerly JCG Industrial Division) |
|
Energy |
OnQuest |
|
Energy |
OnQuest, Canada, ULC |
|
Energy |
Aevenia; acquired February 28, 2015 |
|
Energy |
PES acquired the net assets of two companies, The Saxon Group (Saxon) in 2012 and Force Specialty Services, Inc. (FSSI) in 2013. Effective January 1, 2014, Saxon and FSSI were merged into PES along with the Industrial division of JCG. Throughout this Form 10-K, references to FSSI, Saxon and James Industrial are to the divisions of PES for 2015 and 2014, while the references for 2013 are to the entities or divisions.
ARB owned 50% of the Blythe Power Constructors joint venture (Blythe) created for the installation of a parabolic trough solar field and steam generation system in California, and results of Blythes operations have been included as part of the West segment. The Company determined that in accordance with FASB Topic 810, it was the primary beneficiary of a variable interest entity (VIE) and has consolidated the results of Blythe in its financial statements. The project has been completed, the project warranty expired in May 2015 and dissolution was completed in the third quarter 2015.
ARB owns a 50% interest in two separate joint ventures, both formed in 2015: (1) The Carlsbad Power Constructors joint venture (Carlsbad) will engineer and construct a gas-fired power generation facility and (2) a joint venture titled ARB Inc. & B&M Engineering Co. (Wilmington) will also engineer and construct a co-generation facility. Both projects are located in the Southern California area. The joint venture operations are included as part of the West segment. As a result of determining that the Company is the primary beneficiary of the two VIEs, the results of the Carlsbad and Wilmington joint ventures are consolidated in the Companys financial statements. The Carlsbad project is expected to be completed in 2017 and the Wilmington project in 2018.
Financial information for the joint ventures is presented in Note 13 Noncontrolling Interests.
In January 2014, the Company created a wholly owned subsidiary, BW Primoris, LLC, a Texas limited liability company (BWP). BWPs goal is to develop water projects, primarily in Texas, that will need the Companys construction services. On January 22, 2014, BWP entered into an agreement to purchase the assets and business of Blaus Wasser, LLC, a Wyoming limited liability company, for approximately $5 million. BWP has entered into an intercompany construction contract with Cardinal Contractors, Inc. to build a small water treatment facility which will be owned by BWP. Beginning in 2016, the facility will generate revenues through a take-or-pay contract with a West Texas municipal entity. All intercompany revenue, cost and profit of the construction project was eliminated. At December 31, 2015, a total of $13.8 million has been capitalized, including the acquisition costs, as property, plant and equipment.
In May 2014, the Company created a wholly owned subsidiary, Vadnais, a California company, which on June 5, 2014, purchased the assets of Vadnais Corporation for $6.4 million. Vadnais Corporation was a general contractor specializing in micro-tunneling in California. The assets purchased were primarily equipment, buildings and land. The purchase included a contingent earnout based on meeting certain operating targets. See Note 4Business Combinations for further information.
During the third quarter 2014, the Company made three small purchases totaling $8.2 million acquiring the net assets of Surber Roustabout, LLC (Surber), Ram-Fab, LLC (Ram-Fab) and Williams Testing, LLC (Williams). Surber and Ram-Fab operate as divisions of PES, and Williams is a division of Cardinal Contractors, Inc. Surber provides general oil and gas related construction activities in Texas; Ram-Fab is a fabricator of custom piping systems located in Arkansas; and Williams provides construction services related to sewer pipeline maintenance, rehabilitation and integrity testing in the Florida market. The Surber and Ram-Fab purchases provided for contingent earnout amounts as discussed in Note 4 Business Combinations.
On February 28, 2015, the Company acquired the net assets of Aevenia, Inc. for $22.3 million in cash, and established a new entity, Aevenia, which operates as part of the Companys Energy segment. Headquartered in Moorhead, Minnesota, Aevenia is an energy and electrical construction company which specializes in overhead and underground line work, substations, telecom/fiber, and certain other client-specific on-demand call out services. The majority of their work is delivered under unit-price Master Services Agreements (MSAs). Aevenia has operations in Minnesota, North Dakota, South Dakota and Iowa. The Company believes there are opportunities for Aevenia to grow sales by performing in-house work for other Primoris subsidiaries and to expand the Companys offerings to new geographies in the Midwest United States.
For some end markets we perform the same services in each of our West, East and Energy segments, while for other end markets, such as poured-in-place parking structures, only one of our segments currently serves the market. The following table shows the approximate percentage of revenues over three years derived from our major end-markets, with prior periods conformed to the current year market breakdown:
Market |
|
Twelve Months Ended |
|
Twelve Months Ended |
|
Twelve Months Ended |
|
|
|
|
|
|
|
|
|
Underground capital projects |
|
12 |
% |
17 |
% |
23 |
% |
Utility services |
|
34 |
% |
28 |
% |
29 |
% |
Industrial |
|
16 |
% |
27 |
% |
22 |
% |
Heavy Civil |
|
30 |
% |
22 |
% |
20 |
% |
Engineering |
|
4 |
% |
3 |
% |
2 |
% |
Other |
|
4 |
% |
3 |
% |
4 |
% |
Total |
|
100 |
% |
100 |
% |
100 |
% |
Material trends and uncertainties
We generate our revenue from both large and small construction and engineering projects. The award of these contracts is dependent on many factors, most of which are not within our control. We depend in part on spending by companies in the energy and oil and gas industries, the gas utility industry, as well as municipal water and wastewater customers. Over the past several years, each segment has benefited from demand for more efficient and more environmentally friendly energy and power facilities, local highway and bridge needs and from the activity level in the oil and gas industry; however, each of these industries and the government agencies periodically are adversely affected by macroeconomic conditions. Economic factors outside of our control may affect the amount and size of contracts we are awarded in any particular period.
We closely monitor our customers to assess the effect that changes in economic, market and regulatory conditions may have on them. We have experienced reduced spending by some of our customers over the last several years, which we attribute to negative economic and market conditions, and we anticipate that these negative conditions may continue to affect demand for our services in the near-term. Major fluctuations in market prices of oil, gas and other fuel sources have affected demand for our services. The recent significant reduction in the price of oil has created uncertainty with respect to demand for our oil and gas pipeline and roustabout services in the near term, with additional uncertainty resulting over the length of time that prices will remain depressed. We believe that our upstream operations, such as the construction of gathering lines within the oil shale formations will remain at lower levels for an extended period. We believe that over time, the need for pipeline infrastructure for mid-stream and utility companies will result in a continuing need for our services, but the impact of the low oil prices may delay midstream pipeline opportunities. The continuing changes in the regulatory environment also affects the demand for our services, either by increasing our work or delaying projects. For example, the regulatory environment in California may well result in delays for the construction of gas-fired power plants while the regulators continue to search for significant renewable resources, but the renewable resources may create a demand for our construction services. Finally, we believe that regulated utility customers will continue to invest in our maintenance and replacement services.
Seasonality, cyclicality and variability
Our results of operations are subject to quarterly variations. Some of the variation is the result of weather, particularly rain, ice and snow, which can impact our ability to perform construction services. While the majority of the Companys work is in the southern half of the United States, these seasonal impacts affect revenues and profitability since gas and other utilities defer routine replacement and repair during their period of peak demand. Any quarter can be affected either negatively or positively by atypical weather patterns in any part of the country. In addition, demand for new projects tends to be lower during the early part of the year due to clients internal budget cycles. As a result, the Company usually experiences higher revenues and earnings in the third and fourth quarters of the year as compared to the first two quarters.
The Company is also dependent on large construction projects which tend not to be seasonal, but can fluctuate from year to year based on general economic conditions. Our business may be affected by declines or delays in new projects or by client project schedules. Because of the cyclical nature of our business, the financial results for any period may fluctuate from prior periods, and the Companys financial condition and operating results may vary from quarter-to-quarter. Results from one quarter may not be indicative of its financial condition or operating results for any other quarter or for an entire year.
Two examples of the variability resulting from the combination of seasonality and awards of large projects are as follows. First, in the fourth quarter of 2014, revenues were less than those of the second and third quarters of 2014, primarily reflecting the completion of a large power plant project in 2013. Second, the impact from abnormally wet, rainy weather conditions in the second quarter of 2015 resulted in an unusual decrease in revenues compared to the previous years second quarter.
Critical Accounting Policies and Estimates
GeneralThe preparation of financial statements in conformity with accounting principles generally accepted in the United States requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities and the disclosure of contingent assets and liabilities as of the date of the financial statements and also affect the amounts of revenues and expenses reported for each period. These estimates and assumptions must be made because certain information that is used in the preparation of our financial statements cannot be calculated with a high degree of precision from data available, is dependent on future events, or is not capable of being readily calculated based on generally accepted methodologies. Often, estimates are particularly difficult to determine, and we must exercise significant judgment. Estimates may be used in our assessments of revenue recognition under percentage-of-completion accounting, the allowance for doubtful accounts, useful lives of property and equipment, fair value
assumptions in analyzing goodwill and long-lived asset impairments, self-insured claims liabilities and deferred income taxes. Actual results could differ from those that result from using the estimates under different assumptions or conditions.
An accounting policy is deemed to be critical if it requires an accounting estimate to be based on assumptions about matters that are highly uncertain at the time the estimate is made, and different estimates that reasonably could have been used, or changes in the accounting estimates that are reasonably likely to occur periodically, could materially impact our consolidated financial statements.
The following accounting policies are based on, among other things, judgments and assumptions made by management that include inherent risks and uncertainties. Managements estimates are based on the relevant information available at the end of each period. We periodically review these accounting policies with the Audit Committee of the Board of Directors.
Revenue recognition
Fixed-price contracts Historically, a substantial portion of our revenue has been generated under fixed-price contracts. For fixed-price contracts, we recognize revenues primarily using the percentage-of-completion method, which may result in uneven and irregular results. In the percentage-of-completion method, estimated revenues, estimated contract values and total costs incurred to date are used to calculate revenues earned. Unforeseen events and circumstances can alter the estimate of the costs and potential profit associated with a particular contract. Total estimated costs, and thus contract revenues and profit, can be impacted by changes in productivity, scheduling, the unit cost of labor, subcontracts, materials and equipment. Additionally, external factors such as weather, client needs, client delays in providing permits and approvals, labor availability, governmental regulation and politics may affect the progress of a projects completion and thus the timing of revenue recognition. To the extent that original cost estimates are modified, estimated costs to complete increase, delivery schedules are delayed, or progress under a contract is otherwise impeded, cash flow, revenue recognition and profitability from a particular contract may be adversely affected.
We consider unapproved change orders to be contract variations for which we have customer approval for a change in scope but for which we do not have an agreed upon price change. Costs associated with unapproved change orders are included in the estimated cost to complete the contracts and are treated as project costs as incurred. We recognize revenue equal to costs incurred on unapproved change orders when realization of change order approval is probable. Unapproved change orders involve the use of estimates, and it is reasonably possible that revisions to the estimated costs and recoverable amounts may be required in future reporting periods to reflect changes in estimates or final agreements with customers.
We consider claims to be amounts that we seek, or will seek, to collect from customers or others for customer-caused changes in contract specifications or design, or other customer-related causes of unanticipated additional contract costs on which there is no agreement with customers on both scope and price changes. Claims are included in the calculation of revenue when realization is probable and amounts can be reliably determined. Revenue in excess of contract costs from claims is recognized when an agreement is reached with customers as to the value of the claims, which in some instances may not occur until after completion of work under the contract. Costs associated with claims are included in the estimated costs to complete the contracts and are treated as project costs when incurred.
Other contract forms We also use unit-price, time and material, and cost reimbursable plus fee contracts. For these jobs, revenue is recognized primarily based on contractual terms. For example, time and material contract revenues are generally recognized on an input basis, based on labor hours incurred and on purchases made. Similarly, unit price contracts generally recognize revenue on an output based measurement such as the completion of specific units at a specified unit price.
At any time, if an estimate of total contract cost indicates a loss on a contract, the projected loss is recognized in full at that time. The loss amount is recognized as an accrued loss provision and is included in the accrued expenses and other liabilities amount on the balance sheet. For fixed-price contracts, as the percentage-of-completion method is used to calculate revenues, the accrued loss provision is changed so that the gross profit for the contract remains zero in future periods. The provision for estimated losses on uncompleted contracts was $7.3 million and $2.4 million at December 31, 2015 and 2014, respectively.
Changes in job performance, job conditions and estimated profitability, including those arising from final contract settlements, may result in revisions to costs and income. These revisions are recognized in the period in which the revisions are identified.
In all forms of contracts, we estimate collectability of contract amounts at the same time that we estimate project costs. If we anticipate that there may be issues associated with the collectability of the full amount calculated as revenue, we may reduce the amount recognized as revenue to reflect the uncertainty associated with realization of the eventual cash collection. For example, when a cost reimbursable project exceeds the clients expected budget amount, the client frequently requires an adjustment to the final amount. Similarly, some utility clients reserve the right to audit costs for significant periods after performance of the work. In these situations, we may choose to defer recognition of revenue up to the time that the client pays for the services.
The caption Costs and estimated earnings in excess of billings in the Consolidated Balance Sheet represents unbilled receivables, which arise when revenues have been recorded but the amount will not be billed until a later date. Balances represent: (a) unbilled amounts arising from the use of the percentage-of-completion method of accounting which may not be billed under the terms of the contract until a later date or project milestone, (b) incurred costs to be billed under cost reimbursement type contracts, (c) amounts arising from routine lags in billing, or (d) the revenue associated with unapproved change orders or claims when realization is probable and amounts can be reliably determined. For those contracts in which billings exceed contract revenues recognized to date, the excess amounts are included in the caption Billings in excess of costs and estimated earnings.
In accordance with applicable terms of certain construction contracts, retainage amounts may be withheld by customers until completion and acceptance of the project. Some payments of the retainage may not be received for a significant period after completion of our portion of a project. In some jurisdictions, retainage amounts are deposited into an escrow account.
Valuation of acquired businessesWe use the fair value of the consideration paid and the fair value of the assets acquired and liabilities assumed to account for the purchase price of businesses. The determination of fair value requires estimates and judgments of future cash flow expectations for the assignment of the fair values to the identifiable tangible and intangible assets.
Identifiable Tangible Assets. Significant identifiable tangible assets acquired would include accounts receivable, costs and earnings in excess of billings for projects, inventory and fixed assets (generally consisting of construction equipment) for each acquisition. We determine the fair value of these assets on the acquisition date. For current assets and current liabilities of an acquisition, the Company will evaluate whether the book value is equivalent to fair value due to their short term nature. We estimate the fair value of fixed assets using a market approach, based on comparable market values for similar equipment of similar condition and age.
Identifiable Intangible Assets. When necessary, we use the assistance of an independent third party valuation specialist to determine the fair value of the intangible assets acquired in the acquisitions.
A liability for contingent consideration based on future earnings is estimated at its fair value at the date of acquisition, with subsequent changes in fair value recorded in earnings as a gain or loss. Fair value is estimated as of the acquisition date using estimated earnout payments based on managements best estimate.
Accounting principles generally accepted in the United States provide a measurement period of up to one year in which to finalize all fair value estimates associated with the acquisition of a business. Most estimates are preliminary until the end of the measurement period. During the measurement period, adjustments to initial valuations and estimates that reflect newly discovered information that existed at the acquisition date are recorded. After the measurement date, any adjustments would be recorded as a current period gain or loss.
Goodwill and Indefinite-Lived intangible AssetsGoodwill and certain intangible assets acquired in a business combination and determined to have indefinite useful lives are not amortized but are assessed for impairment annually and more frequently if triggering events occur. In performing these assessments, management relies on various factors, including operating results, business plans, economic projections, anticipated future cash flows, comparable transactions and other market data. There are inherent uncertainties related to these factors and judgment in applying them to the analysis of goodwill for impairment. Since judgment is involved in performing fair value measurements used in goodwill impairment analyses, there is risk that the carrying values of our goodwill may not be properly stated.
We account for goodwill, including evaluation of any goodwill impairment under ASC Topic 350 Intangibles Goodwill and Other, performed at the reporting unit level for those units with recorded goodwill as of October 1 of each year, unless there are indications requiring a more frequent impairment test.
At December 31, 2015, goodwill has arisen from acquisitions and is recorded at our reporting units as follows (in millions):
Reporting Unit |
|
Segment |
|
December 31, |
| |
Rockford |
|
West |
|
$ |
32.1 |
|
Q3C |
|
West |
|
13.2 |
| |
JCG (includes Heavy Civil and Infrastructure and Maintenance divisions) |
|
East |
|
42.9 |
| |
PES (includes PES Industrial, PPS, Saxon & Surber divisions) |
|
Energy |
|
28.4 |
| |
Aevenia |
|
Energy |
|
5.2 |
| |
OnQuest Canada, ULC |
|
Energy |
|
2.4 |
| |
Total Goodwill |
|
|
|
$ |
124.2 |
|
Under ASU 2012-02 - Intangibles Goodwill and Other (Topic 350): Testing Indefinite-Lived Intangible Assets for Impairment, the Company can assess qualitative factors to determine if a quantitative impairment test of intangible assets is necessary. Typically, however, the Company uses the two-step impairment test outlined in ASC Topic 350. First, we compare the fair value of a reporting unit with its carrying amount. Fair value for the goodwill impairment test is determined utilizing a discounted cash flow analysis based on our financial plan discounted using our weighted average cost of capital and market indicators of terminal year cash flows. Other valuation methods may be used to corroborate the discounted cash flow method. If the carrying amount of a reporting unit is in excess of its fair value, goodwill is considered potentially impaired and further tests are performed to measure the amount of impairment loss. In the second step of the goodwill impairment test, we compare the implied fair value of reporting unit goodwill with the carrying amount of the reporting units goodwill. If the carrying amount of the reporting units goodwill exceeds the implied fair value of that goodwill, an impairment loss is recognized in an amount equal to the carrying amount of goodwill over its implied fair value. The implied fair value of goodwill is determined in the same manner that the amount of goodwill recognized in a business combination was determined. We allocate the fair value of a reporting unit to all of the assets and liabilities of that unit, including intangible assets, as if the reporting unit had been acquired in a business combination. Any excess of the fair value of a reporting unit over the amounts assigned to its assets and liabilities represents the implied fair value of goodwill.
In the fourth quarter of 2015, an impairment expense of $0.4 million was recorded relating to the goodwill attributed to Cardinal Contractors, Inc., which is a part of the East Segment, and in December 2013, an impairment expense of $0.8 million was recorded relating to FSSI, a part of the Energy segment, for intangible assets for customer relations. There were no other impairments of goodwill for the years ended December 31, 2015, 2014 and 2013.
Disruptions to our business, such as end market conditions, protracted economic weakness, unexpected significant declines in operating results of reporting units and the divestiture of a significant component of a reporting unit, may result in our having to perform a goodwill impairment first step valuation analysis for some or all of our reporting units prior to the required annual assessment. These types of events and the resulting analysis could result in goodwill impairment charges in any periods in the future.
Reserve for uninsured risksEstimates are inherent in the assessment of our exposure to uninsured risks. Significant judgments by us and, where possible, third-party experts are needed in determining probable and/or reasonably estimable amounts that should be recorded or disclosed in the financial statements. The results of any changes in accounting estimates are reflected in the financial statements of the period in which we determine we need to record a change.
We self-insure workers compensation claims up to $0.25 million per claim. We maintained a self-insurance reserve totaling approximately $26.8 million at December 31, 2015 and approximately $22.3 million at December 31, 2014. Claims administration expenses were charged to current operations as incurred. Our accruals are based on judgment, the probability of losses, and where applicable, the consideration of opinions of internal and/or external legal counsel. The amount is included in accrued expenses and other current liabilities on our balance sheets. Actual payments that may be made in the future could materially differ from such reserves.
Income taxesWe account for income taxes under the asset and liability method as set forth in ASC Topic 740 Income Taxes, which requires the recognition of deferred tax assets and liabilities for the expected future tax consequences of events that have been included in the financial statements. Under this method, deferred tax assets and liabilities are determined based on the temporary differences between the financial statements and tax basis of assets and liabilities using enacted tax rates in effect for the year in which the differences are expected to reverse. The effect of a change in tax rates on net deferred tax assets or liabilities is recognized as an increase or decrease in net income in the period that includes the enactment date.
Deferred income tax assets may be reduced by a valuation allowance if, in the judgment of our management, it is more likely than not that all or a portion of a deferred tax asset will not be realized. In making such determination, we consider all available
evidence, including recent financial operations, projected future taxable income, scheduled reversals of deferred tax liabilities, tax planning strategies, and the length of tax asset carryforward periods. The realization of deferred tax assets is primarily dependent upon our ability to generate sufficient future taxable earnings in certain jurisdictions. If we subsequently determine that some or all deferred tax assets that were previously offset by a valuation allowance are realizable, the value of the deferred tax assets would be increased by reducing the valuation allowance, thereby increasing income in the period when that determination was made.
A tax position is recognized as a benefit only if it is more likely than not that the tax position would be sustained based on its technical merits in a tax examination, using the presumption that the tax authority has full knowledge of all relevant facts regarding the position. The amount recognized is the largest amount of tax benefit that is greater than 50% likely of being realized on ultimate settlement with the tax authority. For tax positions not meeting the more likely than not test, no tax benefit is recorded.
Long-Lived AssetsAssets held and used by the Company, primarily property, plant and equipment, are reviewed for impairment whenever events or changes in business circumstances indicate that the carrying amount of the asset may not be fully recoverable. We perform an undiscounted operation cash flow analysis to determine if an impairment exists. For purposes of recognition and measurement of an impairment for assets held for use, we group assets and liabilities at the lowest level for which cash flows are separately identified. If an impairment is determined to exist, any related impairment loss is calculated based on fair value. The calculation of the fair value of long-lived assets is based on assumptions concerning the amount and timing of estimated future cash flows and assumed discount rates, reflecting varying degrees of perceived risk. Since judgment is involved in determining the fair value and useful lives of long-lived assets, the future carrying value of our long-lived assets may have differing future fair values.
Multiemployer plans Various subsidiaries in the West segment are signatories to collective bargaining agreements. These agreements require that the Company participate in and contribute to a number of multiemployer benefit plans for its union employees at rates determined by the agreements. The trustees for each multiemployer plan determine the eligibility and allocations of contributions and benefit amounts, determine the types of benefits and administer the plan. To the extent that any plans are underfunded, the Employee Retirement Income Security Act of 1974, as amended by the Multi-Employer Pension Plan Amendments Act of 1980, requires that if the Company were to withdraw from an agreement or if a plan is terminated, we may incur a withdrawal obligation. Since the withdrawal liability is based on estimates of our proportional share of the plans unfunded vested liability, as calculated by the plans actuaries, the potential withdrawal obligation may be significant.
In November 2011, members of the Pipe Line Contractors Association PLCA including ARB, Rockford and Q3C (prior to the Companys acquisition in 2012), withdrew from the Central States Southeast and Southwest Areas Pension Fund multiemployer pension plan (Plan). These withdrawals were made in order to mitigate additional liability in connection with the significantly underfunded Plan. The Company recorded a withdrawal liability of $7.5 million, which was increased to $7.59 million after the acquisition of Q3C, based on information provided by the Plan. The Plan asserted that the PLCA members did not affect a proper withdrawal in 2011, and in May 2014, the Plan asserted that the total liability for the Company was $11.8 million. A legal proceeding commenced, and the United States District Court ruled that the withdrawal of the PLCA members in 2011 was not effective. The PLCA appealed this decision, but as required by the Plan, the Company began making monthly payments which have totaled $1.83 million through December 31, 2015. These payments have been expensed.
On September 2, 2015, the U.S. Court of Appeals for the 7th Circuit reversed the decision of the District Court and ruled that the withdrawal was effective in 2011 as had been asserted by the PLCA. The Company has received a revised withdrawal liability calculation from the Plan at an amount approximately equal to the companys accrual amount. The Company and other members of the PLCA are engaged in arbitration to further reduce the amount owed. The Company is making payments while awaiting the results of the arbitration process. The Company has no plans to withdraw from any other agreements
Litigation and contingenciesLitigation and contingencies are included in our consolidated financial statements based on our assessment of the expected outcome of litigation proceedings or the expected resolution of the contingency. We provide for costs related to contingencies when a loss from such claims is probable and the amount is reasonably determinable. In determining whether it is possible to provide an estimate of loss, or range of possible loss, we review and evaluate litigation and regulatory matters on a quarterly basis in light of potentially relevant factual and legal developments. If we determine an unfavorable outcome is not probable or reasonably estimable, we do not accrue for a potential litigation loss. Management is unable to ascertain the ultimate outcome of other claims and legal proceedings; however, after review and consultation with counsel and taking into consideration relevant insurance coverage and related deductibles/self-insurance retention, management believes that it has meritorious defense to the claims and believes that the reasonably possible outcome of such claims will not, individually or in the aggregate, have a materially adverse effect on the consolidated results of operations, financial condition or cash flows of the Company. See Note 15 Commitments and Contingencies in the Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K for further information.
Recently Issued Accounting Pronouncements
See Note 2 Summary of Significant Accounting Policies - Recently Issued Accounting Pronouncements of the Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K for a discussion of recently issued accounting pronouncements.
Results of Operations
Revenue, gross profit, operating income and net income for the years ended December 31, 2015, 2014 and 2013 were as follows:
|
|
2015 |
|
2014 |
|
2013 |
| |||||||||
|
|
(Millions) |
|
% of |
|
(Millions) |
|
% of |
|
(Millions) |
|
% of |
| |||
|
|
|
|
|
|
|
|
|
|
|
|
|
| |||
Revenues |
|
$ |
1,929.4 |
|
100.0 |
% |
$ |
2,086.2 |
|
100.0 |
% |
$ |
1,944.2 |
|
100.0 |
% |
Gross profit |
|
219.9 |
|
11.4 |
% |
236.0 |
|
11.3 |
% |
256.0 |
|
13.2 |
% | |||
Selling, general and administrative expense |
|
152.1 |
|
7.9 |
% |
132.2 |
|
6.3 |
% |
130.8 |
|
6.8 |
% | |||
Operating income |
|
67.8 |
|
3.5 |
% |
103.8 |
|
5.0 |
% |
125.2 |
|
6.4 |
% | |||
Other income (expense) |
|
(6.7 |
) |
(0.3 |
)% |
(1.5 |
) |
(0.1 |
)% |
(5.6 |
) |
(0.2 |
)% | |||
Income before income taxes |
|
61.1 |
|
3.2 |
% |
102.3 |
|
4.9 |
% |
119.6 |
|
6.2 |
% | |||
Provision for income taxes |
|
(23.9 |
) |
(1.3 |
)% |
(38.6 |
) |
(1.9 |
)% |
(44.9 |
) |
(2.3 |
)% | |||
Net income |
|
37.2 |
|
1.9 |
% |
63.7 |
|
3.0 |
% |
74.7 |
|
3.9 |
% | |||
Net income attributable to noncontrolling interests |
|
(0.3 |
) |
(0.0 |
)% |
(0.5 |
) |
(0.0 |
)% |
(5.0 |
) |
(0.3 |
) | |||
Net income to Primoris |
|
$ |
36.9 |
|
1.9 |
% |
$ |
63.2 |
|
3.0 |
% |
$ |
69.7 |
|
3.6 |
% |
Consolidated Results
Revenues
2015 and 2014
Revenues for year ended December 31, 2015 decreased by $156.8 million, or 7.5% compared to the same period in 2014. The decrease was primarily from the impact of unusually severe wet weather in the Gulf States during the first half of 2015 and the completion of two large projects in the Energy segment which were not fully replaced in 2015. The historic rainfall in the first half of the year, especially in the second quarter, caused us to suspend operations on various projects and to incur additional costs to recover from the weather conditions. Revenues were also impacted by the delay in certain capital projects as a result of lower oil prices.
From an end-market perspective, our end-market revenues during the year ended December 31, 2015 decreased by $120.8 million for underground capital projects and the industrial end-market revenues decreased by $252.6 million, as compared to the same period in 2014. For the year ended December 31, 2015, revenues increased in our heavy civil end-market by $123.1 million, in our underground utility end-market by $65.9 million, in the engineering end-market by $9.6 million and by $18.0 million in our other end-markets, as compared to the year ended December 31, 2014.
2014 and 2013
Revenue in 2014 grew to $2.1 billion, an increase of $142.0 million, or 7.3% from the prior year. The increase in revenue at the energy segment of $269.8 million, and at the East segment of $59.5 million, was partially offset by a decline in the West segment of $187.3 million. In 2014, the West segment represented 46.2% of total revenue, the Energy segment represented 30.3%, and the East segment was 23.5% of total revenue. Revenue from acquisitions made in 2014 and 2013 added $18.9 million to revenue.
Gross Profit
2015 and 2014
For the year ended December 31, 2015, gross profit decreased by $16.2 million, or 6.9% compared to the same period in 2014, primarily as a result of the 7.5% decrease in revenues and to inefficiencies associated with stopping and starting projects as a result of the weather delays in the Gulf States during the first half of 2015.
Gross profit as a percentage of revenue increased slightly to 11.4% from 11.3% from the same period in 2014.
2014 and 2013
Gross profit for 2014 decreased by $20.0 million, or 7.8%, from 2013. As discussed in the segment results below, the decrease in gross profit was $47.3 million in the West segment. Gross profit for the Energy segment increased by $25.9 million and increased by $1.4 million for the East segment. Gross profit from acquisitions made in 2014 and 2013 added $3.0 million to 2014 gross profit. Gross profit as a percentage of revenues decreased from 13.2% in 2013 to 11.3% in 2014 as a result of the large decrease in both revenue and gross profit in the West segment
Selling, general and administrative expenses
2015 and 2014
Selling, general and administrative (SG&A) consist primarily of compensation and benefits to executive, management level and administrative employees, marketing and communications, professional fees, office rent and utilities and acquisition costs. For 2015, SG&A expenses were $152.1 million, compared to $132.2 million in 2014, an increase of $19.9 million. Of the increase, $3.9 million was from the 2015 acquisition of Aevenia and $1.6 million of the increase was due to the impact of the 2014 acquisitions of Vadnais, Surber and Ram-Fab. Of the remaining $14.4 million increase, professional fees increased by $9.1 million, we recorded a one-time valuation adjustment for the value of a long-term asset of $2.6 million and the remaining $2.7 million increase represented expenses associated with increased compensation and staffing levels. The majority of the increase in professional fees was an increase in legal fees associated with our collection efforts on the disputed receivables discussed later in this Item and the expenses incurred in our ongoing internal review of the methods used by our subsidiaries to recognize revenue and estimate contingencies for ongoing projects as discussed in the risk factor entitled We may not be successful in continuing to meet the internal control requirements of the Sarbanes Oxley Act of 2002 in Item 1A of this Annual Report on form 10-K. In addition, the increase in professional fees included fees associated with our efforts to improve our documentation of internal controls over financial reporting.
SG&A as a percentage of revenue for the year ended December 31, 2015 increased to 7.9% compared to 6.3% for the year ended December 31, 2014 as a result of both increased expenses and the decrease in revenues in 2015.
2014 and 2013
SG&A expenses were $132.2 million in 2014 compared to $130.8 million in 2013. The prior year included one-time expenses of $5.7 million related to impairment costs. Excluding the one-time expenses, SG&A in 2014 increased $7.1 million, or 5.7%, which included an increase of $1.4 million as a result of the 2014 acquisitions of Vadnais, Surber and Ram-Fab. Remaining increases were due to increases in compensation and benefits, marketing and communications expenses and professional fees.
SG&A expenses as a percentage of revenue decreased to 6.3% for 2014, from 6.7% for 2013.
Other income and expense
Non-operating income and expense items for the years ended December 31, 2015, 2014 and 2013 were as follows:
|
|
2015 |
|
2014 |
|
2013 |
| |||
|
|
(Millions) |
|
(Millions) |
|
(Millions) |
| |||
Other income (expense) |
|
|
|
|
|
|
| |||
Income (loss) from non-consolidated investments |
|
$ |
|
|
$ |
5.3 |
|
$ |
(4.8 |
) |
Foreign exchange gain (loss) |
|
(0.8 |
) |
0.3 |
|
0.2 |
| |||
Other income (expense) |
|
1.7 |
|
(0.8 |
) |
4.8 |
| |||
Interest income |
|
0.1 |
|
0.1 |
|
0.1 |
| |||
Interest expense |
|
(7.7 |
) |
(6.4 |
) |
(5.9 |
) | |||
Total other income (expense) |
|
$ |
(6.7 |
) |
$ |
(1.5 |
) |
$ |
(5.6 |
) |
There was no income from non-consolidated investments for 2015. For 2014, income from non-consolidated investments was primarily from the sale of our interest of the WesPac Energy non-consolidated joint venture, and for 2013, the loss from non-consolidated investments included an impairment expense and operating loss totalling $5.5 million for the WesPac Energy joint venture, partially offset by a $0.7 million profit from a 49% owned investment, Alvah, Inc.
Foreign exchange gains and losses reflect currency exchange fluctuations of the United States dollar compared to the Canadian dollar. Many of our contracts in Calgary, Canada are sold based on United States dollars, but a portion of the work is paid for with Canadian dollars creating a currency exchange difference.
Other income for the year ended December 31, 2015 consisted primarily of the net reversal of $1.9 million in contingent consideration as Ram-Fab, Vadnais and Surber missed financial targets contemplated in their respective purchase agreements. Net other expense of $0.8 million for the year ended December 31, 2014 was due to adjustments to the fair value of the contingent consideration liabilities related to the acquisitions of Q3C, Surber and Vadnais. Net other income for 2013 was $4.8 million. The major components include $6.5 million as reductions in the liability for contingent consideration since the PPS, Saxon and FSSI acquisitions did not meet the performance targets outlined in their purchase agreements. The income was partially offset by increases of $2.5 million in the fair value of the liabilities for contingent consideration recorded throughout 2013 for acquisitions, including Q3C.
Interest income is derived from interest earned on excess cash invested primarily in short term U.S. Treasury bills, backed by the federal government, and other investments that may not be backed by the federal government.
Interest expense for the year ended December 31, 2015 was $7.7 million, compared to $6.4 million for the same period in 2014 due to increased equipment debt financing and additional borrowing under the Companys agreement for senior secured notes. The increased interest expense in 2014 compared to 2013 was due to increases in equipment debt financing, and a full year of interest on a $25 million long-term note drawn-down in July 2013.
The weighted average interest rate on total debt outstanding at December 31, 2015, 2014 and 2013 was 2.9%, 3.0% and 3.3%, respectively.
Provision for income taxes
Our provision for income tax decreased $14.7 million to $23.9 million for 2015 compared to 2014 as a result of the decrease in pretax profits. The effective tax rate on income before provision for income taxes and noncontrolling interests was 39.19% and 37.77% for the years 2015 and 2014, respectively. The effective tax rate excluding income attributable to noncontrolling interests was 39.37% for the year 2015 and 37.96% for 2014. The primary reason for the increase in the effective tax rate was the impact of partially non-deductible per diem expenses, which while decreasing by $5.2 million in 2015, were a greater percentage of pre-tax income.
Our provision for income tax decreased $6.3 million to $38.6 million for 2014 compared to 2013 as a result of decreased pretax profits between the years and a decrease in our effective tax rate.
Segment Results
The following discussion describes the significant factors contributing to the results of our three operating segments. All intersegment revenues and gross profit, which were immaterial, have been eliminated in the following tables.
West Segment
Revenue and gross profit for the West segment for the years ending December 31, 2015, 2014 and 2013 were as follows:
|
|
2015 |
|
2014 |
|
2013 |
| |||||||||
|
|
(Millions) |
|
% of |
|
(Millions) |
|
% of |
|
(Millions) |
|
% of |
| |||
West Construction Services |
|
|
|
|
|
|
|
|
|
|
|
|
| |||
Revenue |
|
$ |
913.6 |
|
|
|
$ |
964.1 |
|
|
|
$ |
1,151.4 |
|
|
|
Gross profit |
|
$ |
130.3 |
|
14.3 |
% |
$ |
143.5 |
|
14.9 |
% |
$ |
190.7 |
|
16.6 |
% |
2015 and 2014
West segment revenue for 2015 decreased by $50.5 million, or 5.2%, compared to 2014. Revenue declined at the ARB Industrial division by $105.0 million with $80.2 million of the decrease the result of completion of a solar plant project in the Mojave Desert in 2014. The decrease was partially offset by increases at ARB Structures and Q3C totaling $62.2 million. The ARB Structures revenue increase was driven primarily by work on a large parking structure in southern California, and the Q3C revenue increase was attributable primarily to additional work performed for its largest customer, a gas and electric utility, totaling $27.6 million.
Gross profit for the West segment decreased by $13.2 million or 9.2% for 2015 versus 2014. The primary reason was a reduction of gross profit at both ARB Industrial and Rockford totaling $17.4 million, offset by an increase at ARB Underground of $5.1 million. The declines were due to the reduction in revenue at ARB Industrial and the impact of the rain in the second quarter on the pipeline operations of Rockford. The increase realized by ARB Underground was driven largely by increased MSA work performed for a major public gas and electric utility customer under its Pipeline Safety Enhancement Plan.
Gross profit as a percentage of revenues decreased to 14.3% in 2015 compared to 14.9% in 2014, still consistent with historical ratios. This decline in margin is largely attributable to Rockfords margin decrease from 11.6% in 2014 to 8.6% in 2015 reflecting a reduced level of work in the fourth quarter of 2015 and the impact of the rainy weather on a large diameter pipeline job in the Houston, TX area.
2014 and 2013
West segment revenue in 2014 decreased by $187.3 million, or 16.3%, compared to 2013. Revenue declined at Rockford by $175.6 million primarily as a result of the completion of several large projects in 2013 and a $102 million decrease for a customer in the Marcellus shale region. Revenue decreased by $41.8 million at the ARB Underground division primarily due to reduced revenue of $23.2 million from traditional MSA customers, a decline of $40.1 million for one-time projects completed in 2013 partially offset by an increase in pipeline integrity work for a large gas utility customer. ARB Industrial division revenues declined by $21.8 million as a result of an $84.3 million decrease from the substantial completion of a major power plant project in 2013. The decrease was partially offset by an increase of $53.2 million for construction of a solar plant project in the Mojave Desert in 2014. Finally, revenue at Q3C increased $62.2 million compared to 2013 due primarily to increase in work for a large utility located in the north central United States.
Gross profit for the West segment decreased by $47.3 million or 24.8%. The primary reason for the decrease was a reduction of gross profit at ARB of $54.3 million. The declines were due to a combination of the close out of a major power plant project, the substantial completion of the Blythe joint venture project, the mix of MSA jobs at ARB Underground and the decline in revenue including $4.4 million less equipment cost absorption by the jobs as a result of the lower activity levels in 2014 compared to 2013. Gross profit at Rockford decreased by $5.1 million while gross profit at Q3C increased by $13.5 million, with the revenue at the operating units serving as the primary driver of gross profit changes.
Gross profit as a percentage of revenues decreased to 14.9% in 2014 compared to 16.6% in 2013. The percentage in 2013 was higher than our historical percentages, which have ranged from 13% to 16% of revenue as a result of the substantial completion in 2013 of a power plant project by the ARB Industrial division. In addition, ARB Industrial recorded revenue of $29.5 million in 2013 and revenue of $82.6 million in 2014 for construction services at a large solar project in the Mojave Desert. Because of uncertainty as to collectability at the end of the cost-reimbursable project, we recorded revenues equal to cost for this project. Excluding the revenue and cost of this project, gross profit as a percentage of revenues would have been 16.3% for 2014 compared to 17.0% for 2013.
East Segment
Revenue and gross profit for the East segment for the years ended December 31, 2015, 2014 and 2013 were as follows:
|
|
2015 |
|
2014 |
|
2013 |
| |||||||||
|
|
(Millions) |
|
% of |
|
(Millions) |
|
% of |
|
(Millions) |
|
% of |
| |||
East Construction Services |
|
|
|
|
|
|
|
|
|
|
|
|
| |||
Revenue |
|
$ |
612.2 |
|
|
|
$ |
489.9 |
|
|
|
$ |
430.4 |
|
|
|
Gross profit |
|
$ |
42.5 |
|
6.9 |
% |
$ |
25.7 |
|
5.3 |
% |
$ |
24.3 |
|
5.6 |
% |
2015 and 2014
East segment revenue for the year ended December 31, 2015 increased by $122.2 million, or 25.0% from 2014. The increase was due primarily to JCGs infrastructure and maintenance division work at a large petrochemical facility project in Louisiana.
East segment gross profit for the year ended December 31, 2015 increased by $16.8 million, or 65.1%, compared to 2014. The increase was due primarily to the increased revenue for the JCG infrastructure and maintenance division petrochemical project in Louisiana. Gross profit decreased at both JCGs heavy civil division and Cardinal Contractors. Gross profit for JCG heavy civil division projects decreased by $15.3 million primarily from delays at the Texas DOT projects in the Belton, TX area, and Cardinal Contractors gross profits decreased by $4.9 million, primarily from reduced margins for two Texas wastewater projects.
Gross profit as a percentage of revenues increased to 6.9 % in 2015 compared to 5.3% in 2014 primarily as a result of the increase in revenues.
2014 and 2013
Revenue for the East segment increased by $59.5 million, or 13.8% from 2013. Of the increase, $66.1 million was at JCGs heavy civil and infrastructure and maintenance divisions due primarily to increases of $42.8 million in Texas DOT revenue and an increase of $40.2 million in Mississippi DOT revenue. The increases were partially offset by a reduction of $19.1 million in Louisiana DOT revenue. Additionally, Cardinal Contractors revenue decreased by $8.9 million, reflecting decreased work in the wastewater facility market in Florida.
Gross profit for the East segment increased by $1.4 million, or 5.9%, compared to 2013. The increased percentage was lower than the revenue growth primarily as a result of reduced gross profit of $1.9 million for JCG heavy civil projects offset by increases of $1.8 million at JCGs infrastructure and maintenance divisions and $0.6 million for Cardinal Contractors projects. Heavy civil experienced a $7.9 million decrease in gross profit due to both the impact of the lower Louisiana DOT revenues and reduced gross profit on Texas DOT work. This decrease was partially offset by gross profit increases of $5.6 million in other heavy civil work, primarily on Mississippi DOT projects.
Gross profit as a percentage of revenues decreased to 5.3 % in 2014 compared to 5.6% in 2013 primarily as a result of the lower gross profit Texas and Louisiana heavy civil projects.
Energy Segment
Revenue and gross profit for the Energy segment for the years ended December 31, 2015, 2014 and 2013 were as follows:
|
|
2015 |
|
2014 |
|
2013 |
| |||||||||
|
|
(Millions) |
|
% of |
|
(Millions) |
|
% of |
|
(Millions) |
|
% of |
| |||
Energy Segment |
|
|
|
|
|
|
|
|
|
|
|
|
| |||
Revenue |
|
$ |
403.6 |
|
|
|
$ |
632.2 |
|
|
|
$ |
362.4 |
|
|
|
Gross profit |
|
$ |
47.1 |
|
11.7 |
% |
$ |
66.8 |
|
10.6 |
% |
$ |
40.9 |
|
11.3 |
% |
2015 and 2014
Revenue for the Energy segment decreased by $228.6 million, or 36.2% from 2014. The PES Industrial division revenue decreased by $116.0 million, primarily due to completion of a fertilizer plant project in 2014, and the impact of the unusually severe rainy weather during the first half of the year, which delayed our ability to start work for a chemical plant project in Louisiana. PESs pipeline division revenue decreased by $113.9 million as a result of completion of a pipeline project in 2014. For the PES Saxon division, revenue decreased by $36.6 million as a result of a 2014 completion of a project in the Houston Ship Channel, partially offset by increases from two projects in Pennsylvania. OnQuest and OnQuest Canada revenue in 2015 increased by $9.6 million as a result of an LNG project in Florida. Revenue for Aevenia, acquired on February 28, 2015, was $23.7 million.
Gross profit for the Energy segment decreased by $19.8 million, or 29.5% for the year ended December 31, 2015, compared to 2014. The PES industrial division, PES pipeline division and the PES Saxon division gross profit decreased $27.1 million as a result of the reduction in revenue. PESs Specialty division gross profit increased $3.6 million as a result of the completion of a chilled water project in Texas. Aevenias gross profit was $2.4 million.
Gross profit as a percentage of revenues increased to 11.7% in 2015 compared to 10.6% in 2014. The increase was primarily the result of two offsetting factors. The first was due to the effect of zero margin work on a large pipeline project at the PES Pipeline division in 2014 and its resulting lower prior year gross profit margin percentage. Offsetting this was reduced 2015 gross profits caused by the heavy rains during the first half of 2015 and decreased labor efficiency rates.
2014 and 2013
Revenue for the Energy segment increased by $269.8 million, or 74.5% from 2013. The PES Industrial division revenue increased by $129.0 million primarily from work activity at petrochemical facilities in south Louisiana. PESs PPS division revenue increased by $85.5 million as a result of increased revenues from capital projects. PESs Saxon division revenue increased by $17.1
million and OnQuest and OnQuest Canada revenue in 2014 increased by $21.5 million as a result of additional revenue from construction of a micro LNG facility in 2014.
Gross profit for the Energy segment increased by $25.9 million, or 63.1%, compared to 2013. The PES Industrial division gross profit increased $14.6 million primarily due to the divisions increased revenues. PESs PPS division gross profit increased $4.1 million due to increased revenues and the Saxon division gross profit increased $3.7 million as a result of increased revenues and improved profit margins compared to 2013. OnQuest and OnQuest Canada profit margins in 2014 increased by $1.5 million due to increased revenues.
Gross profit as a percentage of revenues decreased to 10.6% in 2014 compared to 11.3% in 2013 primarily as a result of the reduced margins at PESs PPS division. Similar to ARB Industrial, PPS recorded revenues equal to cost for a large pipeline project for which we have concerns about collectability of the full contractual amount. In 2013, PPS recorded revenue of $9.2 million and in 2014, PPS recorded revenue of $121.2 million for the project. Excluding the revenue of this project, gross profit as a percentage of revenues would have been 13.0% for 2014 compared to 11.6% for 2013.
Liquidity and Capital Resources
Cash Needs
Liquidity represents our ability to pay our liabilities when they become due, fund business operations and meet our contractual obligations and execute our business plan. Our primary sources of liquidity are our cash balances at the beginning of each period and our net cash flow. If needed, we have availability under our lines of credit to augment liquidity needs. In order to maintain sufficient liquidity, we evaluate our working capital requirements on a regular basis. We may elect to raise additional capital by issuing common stock, convertible notes, term debt or increasing our credit facility as necessary to fund our operations or to fund the acquisition of new businesses.
Our cash and cash equivalents totaled $161.1 million at December 31, 2015 compared to $170.5 million at December 31, 2014. We anticipate that our cash and investments on hand, existing borrowing capacity under our credit facility and our future cash flows from operations will provide sufficient funds to enable us to meet our operating needs, our planned capital expenditures and our ability to grow for at least the next twelve months.
The construction industry is capital intensive, and we expect to continue to make capital expenditures to meet anticipated needs for our services. Historically, we have invested an amount that approximated the sum of depreciation and amortization expenses plus proceeds from equipment sales. In 2015, capital expenditures were approximately $67.1 million. For 2015, the amount of depreciation, amortization and equipment sales was approximately $75.1 million. Capital expenses are expected to total $55 to $60 million for 2016.
Cash Flows
Cash flows during the years ended December 31, 2015, 2014 and 2013 are summarized as follows:
|
|
2015 |
|
2014 |
|
2013 |
| |||
|
|
(Millions) |
|
(Millions) |
|
(Millions) |
| |||
Change in cash |
|
|
|
|
|
|
| |||
Net cash provided by operating activities |
|
$ |
48.4 |
|
$ |
36.1 |
|
$ |
77.7 |
|
Net cash used in investing activities |
|
(48.5 |
) |
(102.6 |
) |
(97.1 |
) | |||
Net cash provided by financing activities |
|
21.8 |
|
9.9 |
|
57.9 |
| |||
Net change in cash |
|
$ |
21.7 |
|
$ |
(56.6 |
) |
$ |
38.5 |
|
Operating Activities
The source of our cash flow from operating activities and the use of a portion of that cash in our operations for the years ended December 31, 2015, 2014 and 2013 were as follows:
|
|
2015 |
|
2014 |
|
2013 |
| |||
|
|
(Millions) |
|
(Millions) |
|
(Millions) |
| |||
Operating Activities |
|
|
|
|
|
|
| |||
Operating income |
|
$ |
67.8 |
|
$ |
103.8 |
|
$ |
125.2 |
|
Depreciation and amortization |
|
65.2 |
|
58.4 |
|
49.9 |
| |||
Gain on sale of property and equipment |
|
(2.1 |
) |
(1.9 |
) |
(1.4 |
) | |||
Stock-based compensation expense |
|
1.0 |
|
0.9 |
|
0.3 |
| |||
Distributions received from non-consolidated entities |
|
|
|
|
|
2.8 |
| |||
Other than temporary impairment expense for non-consolidated entities |
|
|
|
|
|
4.0 |
| |||
Goodwill/Intangible asset impairment |
|
0.4 |
|
|
|
0.8 |
| |||
Net deferred taxes |
|
(7.0 |
) |
9.0 |
|
(12.6 |
) | |||
Changes in assets and liabilities |
|
(46.3 |
) |
(88.7 |
) |
(45.6 |
) | |||
Foreign exchange gain (loss) |
|
(0.8 |
) |
0.3 |
|
0.2 |
| |||
Interest income |
|
0.1 |
|
0.1 |
|
0.1 |
| |||
Interest expense |
|
(7.7 |
) |
(6.4 |
) |
(5.9 |
) | |||
Other income (expense) |
|
1.7 |
|
(0.8 |
) |
4.8 |
| |||
Provision for income taxes |
|
(23.9 |
) |
(38.6 |
) |
(44.9 |
) | |||
Net cash provided by operating activities |
|
$ |
48.4 |
|
$ |
36.1 |
|
$ |
77.7 |
|
Net cash provided by operating activities for 2015 of $48.4 million increased by $12.3 million compared to 2014. This increase was caused by the $6.8 million increase in depreciation and amortization, the reduced provision for income taxes of $14.7 million, offset by the decrease in operating income of $36.0 million and due to the $46.3 million net changes in assets and liabilities in 2015 compared to the net change of $88.7 million in 2014.
The components of the $46.3 million change in assets and liabilities for the year ended December 31, 2015 are summarized as follows:
· an increase of $2.1 million in customer retention deposits;
· a decrease of $19.5 million in accounts receivable, primarily as a result of a decrease of $17.7 million in amounts retained by customers as we have completed major projects. At December 31, 2015, accounts receivable represented 28.3% of our total assets compared to 30.4% at the end of 2014. In general, we continue to maintain an excellent collection history, and we have certain lien rights that can provide additional security for collections. However, as outlined in the section Receivable Collection Actions, we are in dispute resolution with two customers with a total receivable amount $50.8 million, or 16.0% of our total accounts receivable balance at December 31, 2015;
· an increase of $47.5 million in costs and estimated earnings in excess of billings. Increases associated with the time lag from when revenues were earned until the customer can be billed were approximately $23.6 million for ARB, primarily for two large utility customers, and $22.6 million for JCG, primarily for public agency heavy civil projects which require inspector approval prior to billing;
· a decrease in inventory and other current assets of $4.9 million primarily as a result of the 2015 utilization of the prior year tax receivable;
· accounts payable decreased by $5.1 million, primarily impacted by the timing of vendor payments;
· a net decrease of $19.6 million in billings in excess of costs and estimated earnings reflecting the timing of work progression and billings;
· a decrease of $6.7 million in contingent earn-out liabilities, from a payment of $5.0 million made in March 2015 and the reduction of the earn-out liability as a result of the Ram-Fab, Vadnais and Surber operations not meeting targets outlined in their purchase agreements; and
· a net increase of $11.7 million in accrued expenses, mainly due to an increase in workers compensation reserves.
During the twelve months of 2015, we paid $18.7 million for income taxes compared to $57.6 million in the same period of the previous year. The reduction in net cash tax payments in 2015 was the result of a decrease in the Companys current tax provision and the utilization of significant prepayments from 2014.
Investing activities
|
|
2015 |
|
2014 |
|
2013 |
| |||
|
|
(Millions) |
|
(Millions) |
|
(Millions) |
| |||
Capital expenditures cash |
|
$ |
67.1 |
|
$ |
88.0 |
|
$ |
87.1 |
|
Capital expenditures financed |
|
|
|
|
|
2.6 |
| |||
Total capital expenditures |
|
$ |
67.1 |
|
$ |
88.0 |
|
$ |
89.7 |
|
We purchased property and equipment for $67.1 million, $88.0 million and $89.7 million in the years ended December 31, 2015, 2014 and 2013, respectively, principally for our construction activities. We believe the ownership of equipment is generally preferable to renting equipment on a project-by-project basis, as ownership helps to ensure the equipment is available for our workloads when needed. In addition, ownership has historically resulted in lower overall equipment costs.
We periodically sell equipment, typically to update our fleet. We received proceeds from the sale of used equipment of $9.9 million, $5.8 million and $7.9 million for 2015, 2014 and 2013, respectively.
During 2015, we did not purchase any short-term investments, while we invested $33.8 million and $23.1 million in 2014 and 2013, respectively, in short-term investments. We sold short-term investments amounting to $31.0 million, $21.5 million and $7.4 million in 2015, 2014 and 2013, respectively. Short-term investments consisted primarily of U.S. Treasury bills with various financial institutions.
We used $22.3 million in cash for the Aevenia acquisition, $14.6 million in cash for the Vadnais and Surber/Ram-Fab/Williams acquisitions in 2014 and $2.3 million in cash for the FSSI acquisition in 2013.
Financing activities
Financing activities provided cash of $21.8 million in 2015. Significant transactions impacting cash flows from financing activities included:
· $50.3 million in new and refinanced notes secured by our equipment and by a mortgage note on two buildings;
· $25.0 million in new debt under the Companys Note Agreement;
· $43.9 million in repayment of long-term debt and the repayment of $1.3 million in capital leases;
· $0.03 million in payments of accumulated earnings to the Blythe non-controlling interest holder;
· Dividend payments of $9.8 million to our stockholders during the year ended December 31, 2015; and
· $1.6 million in proceeds from the issuance of 96,828 shares of common stock purchased by the participants in the Primoris Long-term Retention Plan.
Debt Activities
Revolving Credit Facility
As of December 31, 2015, the Company had a revolving credit facility, as amended on December 12, 2014 (the Credit Agreement) with The PrivateBank and Trust Company, as administrative agent (the Administrative Agent) and co-lead arranger, The Bank of the West, as co-lead arranger, and IBERIABANK Corporation, Branch Banking and Trust Company and UMB Bank, N.A. (the Lenders). The Credit Agreement is a $125 million revolving credit facility whereby the Lenders agree to make loans on a revolving basis from time to time and to issue letters of credit for up to the $125 million committed amount. The termination date of the Credit Agreement is December 28, 2017.
The principal amount of any loans under the Credit Agreement will bear interest at either: (i) LIBOR plus an applicable margin as specified in the Credit Agreement (based on the Companys senior debt to EBITDA ratio as that term is defined in the Credit Agreement), or (ii) the Base Rate (which is the greater of (a) the Federal Funds Rate plus 0.5% or (b) the prime rate as announced by the Administrative Agent). Quarterly non-use fees, letter of credit fees and administrative agent fees are payable at rates specified in the Credit Agreement.
The principal amount of any loan drawn under the Credit Agreement may be prepaid in whole or in part, with a minimum prepayment of $5 million, at any time, potentially subject to make-whole provisions.
The Credit Agreement includes customary restrictive covenants for facilities of this type, as discussed below.
Commercial letters of credit outstanding were $12.1 million at December 31, 2015 and $4.7 million at December 31, 2014. Other than commercial letters of credit, there were no borrowings under this line of credit during the twelve months ended December 31, 2015, and available borrowing capacity at December 31, 2015 was $112.9 million.
Senior Secured Notes and Shelf Agreement
On December 28, 2012, the Company entered into a $50 million Senior Secured Notes purchase (Senior Notes) and a $25 million private shelf agreement (the Notes Agreement) by and among the Company, The Prudential Investment Management, Inc. and certain Prudential affiliates (the Noteholders). On June 3, 2015, the Notes Agreement was amended to provide for the issuance of additional notes of up to $75 million over the next three year period ending June 3, 2018 (Additional Senior Notes).
The Senior Notes amount was funded on December 28, 2012. The Senior Notes are due December 28, 2022 and bear interest at an annual rate of 3.65%, paid quarterly in arrears. Annual principal payments of $7.1 million are required from December 28, 2016 through December 28, 2021 with a final payment due on December 28, 2022. The principal amount may be prepaid, with a minimum prepayment of $5 million, at any time, subject to make-whole provisions.
On July 25, 2013, the Company drew $25 million available under the Notes Agreement. The notes are due July 25, 2023 and bear interest at an annual rate of 3.85% paid quarterly in arrears. Seven annual principal payments of $3.6 million are required from July 25, 2017 with a final payment due on July 25, 2023.
On November 9, 2015, the Company drew $25 million available under the Additional Senior Notes Agreement. The notes are due November 9, 2025 and bear interest at an annual rate of 4.6% paid quarterly in arrears. Seven annual principal payments of $3.6 million are required from November 9, 2019 with a final payment due on November 9, 2025.
Loans made under both the Credit Agreement and the Notes Agreement are secured by our assets, including, among others, our cash, inventory, goods, equipment (excluding equipment subject to permitted liens) and accounts receivable. All of our domestic subsidiaries have issued joint and several guaranties in favor of the Lenders and Noteholders for all amounts under the Credit Agreement and Notes Agreement.
Both the Credit Agreement and the Notes Agreement contain various restrictive and financial covenants including among others, minimum tangible net worth, senior debt/EBITDA ratio, debt service coverage requirements and a minimum balance for unencumbered net book value for fixed assets. In addition, the agreements include restrictions on investments, change of control provisions and provisions in the event the Company disposes more than 20% of its total assets.
The Company was in compliance with the covenants for the Credit Agreement and Notes Agreement at December 31, 2015.
Canadian Credit Facility
The Company has a demand credit facility for $8.0 million in Canadian dollars with a Canadian bank for purposes of issuing commercial letters of credit in Canada. The credit facility has an annual renewal and provides for the issuance of commercial letters of credit for a term of up to five years. The facility provides for an annual fee of 1% for any issued and outstanding commercial letters of credit. Letters of credit can be denominated in either Canadian or U.S. dollars. At December 31, 2015 and 2014, letters of credit outstanding totaled $2.2 million and $2.6 million in Canadian dollars, respectively. At December 31, 2015, the available borrowing capacity was $5.8 million in Canadian dollars. The credit facility contains a working capital restrictive covenant for our Canadian subsidiary, OnQuest Canada, ULC. At December 31, 2015, OnQuest Canada, ULC was in compliance with the covenant.
Contractual Obligations
As of December 31, 2015, we had $275.3 million of outstanding long-term debt and capital lease obligations. There were no short-term borrowings.
A summary of contractual obligations as of December 31, 2015 were as follows:
|
|
Total |
|
1 Year |
|
2 - 3 Years |
|
4 - 5 Years |
|
After 5 Years |
| |||||
|
|
(In Millions) |
| |||||||||||||
Long-term debt and capital lease obligations |
|
$ |
275.3 |
|
$ |
55.4 |
|
$ |
97.1 |
|
$ |
73.1 |
|
$ |
49.7 |
|
Interest on long-term debt (1) |
|
30.6 |
|
7.5 |
|
11.2 |
|
6.5 |
|
5.4 |
| |||||
Equipment operating leases |
|
14.2 |
|
6.8 |
|
5.3 |
|
1.8 |
|
0.3 |
| |||||
Real property leases |
|
11.2 |
|
3.4 |
|
5.8 |
|
2.0 |
|
|
| |||||
Real property leasesrelated parties |
|
7.6 |
|
1.5 |
|
2.6 |
|
1.7 |
|
1.8 |
| |||||
|
|
$ |
338.9 |
|
$ |
74.6 |
|
$ |
122.0 |
|
$ |
85.1 |
|
$ |
57.2 |
|
Letters of credit |
|
$ |
13.7 |
|
$ |
8.7 |
|
$ |
5.0 |
|
$ |
|
|
|
|
(1) The interest amount represents interest payments for our fixed rate debt assuming that principal payments are made as originally scheduled.
The table does not include obligations under multi-employer pension plans in which some of our employees participate. Our multi-employer pension plan contribution rates are generally specified in our collective bargaining agreements, and contributions are made to the plans based on employee payrolls. Our obligations for future periods cannot be determined because we cannot predict the number of employees that we will employ at any given time nor the plans in which they may participate.
We may also be required to make additional contributions to multi-employer pension plans if they become underfunded, and these contributions will be determined based on our union payroll. The Pension Protection Act of 2006 added special funding and operational rules for multi-employer plans that are classified as endangered, seriously endangered or critical status. Plans in these classifications must adopt measures to improve their funded status through a funding improvement or rehabilitation plan, which may require additional contributions from employers. The amounts of additional funds that we may be obligated to contribute cannot be reasonably estimated and is not included in the table above.
In November 2011, members of the Pipe Line Contractors Association (PLCA), including ARB, Rockford and Q3C (prior to the Companys acquisition in 2012), withdrew from the Central States Southeast and Southwest Areas Pension Fund multiemployer pension plan (Plan). These withdrawals were made in order to mitigate additional liability in connection with the significantly underfunded Plan. The Company recorded a withdrawal liability of $7.5 million, which was increased to $7.6 million after the acquisition of Q3C, based on information provided by the Plan. The Plan asserted that the PLCA members did not affect a proper withdrawal in 2011, and in May 2014, the Plan asserted that the total liability for the Company was $11.8 million. A legal proceeding commenced, and a United States District Court ruled that the withdrawal of the PLCA members in 2011 was not effective. The PLCA appealed this decision, but as required by the Plan, the Company began making monthly payments which have totaled $1.8 million through December 31, 2015. These payments have been expensed.
On September 2, 2015, the U.S. Court of Appeals for the 7th Circuit reversed the decision of the District Court and ruled that the withdrawal was effective in 2011 as had been asserted by the PLCA. The Company has received a revised withdrawal liability calculation from the Plan at an amount approximately equal to the companys accrual amount. The Company and other members of the PLCA are engaged in arbitration to further reduce the amount owed. The Company is making payments while awaiting the results of the arbitration process. The Company has no plans to withdraw from any other agreements.
We have also excluded from the table any interest and fees associated with letters of credit and commitment fees under our credit facility since these amounts are unknown and variable.
Related Party Transactions
Primoris has entered into leasing transactions with Stockdale Investment Group, Inc. (SIGI). Brian Pratt, our Chairman of the Board of Directors and our largest stockholder, holds a majority interest and is the chairman, president and chief executive officer and a director of SIGI. John M. Perisich, our Executive Vice President and General Counsel, is secretary of SIGI.
Primoris leases properties from SIGI at the following locations:
1. Bakersfield, California (lease expires October 2022)
2. Pittsburg, California (lease expires April 2023)
3. San Dimas, California (lease expires March 2019)
During the years ended December 31, 2015, 2014 and 2013, the Company paid $0.83 million, $0.86 million and $0.91 million, respectively, in lease payments to SIGI for the use of these properties.
Primoris leases a property from Roger Newnham, a former owner and current manager of our subsidiary, OnQuest Canada, ULC. The property is located in Calgary, Canada. During the years ended December 31, 2015, 2014 and 2013 Primoris paid $0.25 million, $0.29 million and $0.30 million, respectively, in lease payments. The current term of the lease will expire on December 31, 2017.
Primoris leases a property from Lemmie Rockford, one of the Rockford sellers, which commenced November 1, 2011. The property is located in Toledo, Washington. During the years ended December 31, 2015, 2014 and 2013, Primoris paid $0.09 million each year, in lease payments. The lease will expire in January 2017.
Primoris leases a property from Quality RE Partners, owned by three of the Q3C selling shareholders, of whom two are current employees, including Jay Osborn, an operations president in the West Construction segment. The property is located in Little
Canada, Minnesota. During the years ended December 31, 2015, 2014 and 2013, the Company paid $0.27 million, $0.26 million and $0.26 million, respectively, in lease payments to Quality RE Partners. The lease expires in October 2022. In addition, in November 2015, Q3C purchased construction equipment at fair value from Quality RE Partners for $0.6 million. Q3C also leased construction equipment from Mr. Osborn during 2015 for $0.04 million and subsequently purchased the equipment at fair value for $0.145 million.
We believe that the amounts that we pay for the leases approximate terms that we could obtain from independent third parties. In addition, related party transactions, any new leases, extensions of lease terms and changes in lease terms or amounts must be approved in advance by the independent directors of the Board of Directors Audit Committee.
Off Balance Sheet Transactions
As is common in our industry, we enter into certain off-balance sheet arrangements in the ordinary course of business that result in risks not directly reflected on our balance sheet. We have no off-balance sheet financing arrangement with variable interest entities. The following represent transactions, obligations or relationships that could be considered material off-balance sheet arrangements.
· Letters of credit issued under our lines of credit. At December 31, 2015, we had letters of credit outstanding of $13.7 million, primarily for international projects in our Energy segment, a large domestic pipeline project and for providing security to our insurance carriers. These letters of credit are used by some of our carriers to ensure reimbursement for amounts that they are disbursing on our behalf, such as beneficiaries under our self-funded insurance program. In addition, from time to time, certain customers require us to post a letter of credit to ensure payments to our subcontractors or guarantee performance under our contracts. Letters of credit reduce our borrowing availability under our Credit Agreement and Canadian Credit Facility. If these letters of credit were drawn on by the beneficiary, we would be required to reimburse the issuer of the letter of credit, and we may be required to record a charge to earnings for the reimbursement. We do not believe that it is likely that any material claims will be made under a letter of credit.
· We enter into non-cancellable operating leases for some of our facilities, equipment and vehicles, including leases with related parties. At December 31, 2015, equipment operating leases had a remaining commitment of $14.2 million and facility rental commitments were $18.8 million.
· Employment agreements which provide for compensation and benefits under certain circumstances and which may contain a change of control clause. We may be obligated to make payments under the terms of these agreements.
· In the ordinary course of our business, we may be required by our customers to post surety bid or completion bonds in connection with services that we provide. At December 31, 2015, we had $1.48 billion in outstanding bonds. We do not believe that it is likely that we would have to fund material claims under our surety arrangements.
· Certain of our subsidiaries are parties to collective bargaining agreements with unions. In most instances, these agreements require that we contribute to multi-employer pension and health and welfare plans. For many plans, the contributions are determined annually and required future contributions cannot be determined since contribution rates depend on the total number of union employees and actuarial calculations based on the demographics of all participants. The Employee Retirement Income Security Act of 1974 (ERISA), as amended by the Multi-Employer Pension Amendments Act of 1980, subject employers to potential liabilities in the event of an employers complete or partial withdrawal of an underfunded multi-employer pension plan. The Pension Protection Act of 2006 added new funding rules that are classified as endangered, seriously endangered, or critical status. As discussed in Note 18 Multiemployer Plans of the Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K, we have recognized a withdrawal liability for one plan. We currently do not anticipate withdrawal from any other multi-employer pension plans. Withdrawal liabilities or requirements for increased future contributions could negatively impact our results of operations and liquidity; and
· Other guarantees that we make from time to time, such as guaranteeing the obligations of our subsidiaries.
Receivable Collection Actions
As all construction contractors, we negotiate payments with our customers from time to time, and we may encounter delays in receiving payments from our customers. However, in 2014, we encountered unusual situations with two contracts. In one instance, ARB Industrial performed work on a solar plant in the Mojave Desert. Based on our concerns about eventual collectability for the cost-reimbursable contract and in spite of many assurances of payment from the owner, we chose to recognize revenue equal to cost. At the end of the project, the owner chose not to pay the final amounts due totaling $32.9 million. We are currently engaged in
alternative dispute resolution as required by the contract. The owner has bonded around the liens that we filed, and we believe that action will enhance collectability of amounts due at the end of the dispute process.
In addition, a division of PES constructed a large capital pipeline for a customer in Texas. During the early stages of the project, we became concerned that the customer would not pay us for ancillary items as we believe is required by the contract. As a result of our concerns about eventual collectability, we chose to recognize revenue equal to cost. We have initiated legal action and filed liens to collect our $17.9 million receivable.
The Company has specific reserves of approximately $26 million for these two projects included in billings in excess of costs and estimated earnings. While we believe that in both instances we are owed the full amount of the receivable, there can be no guarantee of the final amount that we receive or the timing of a resolution of the two matters.
2016 Outlook
We believe that we have market growth opportunities in 2016 and well into 2017 even if the price of oil remains at a depressed level for 2016. We do note that the increasingly stringent regulatory and environmental requirements for many of our clients infrastructure improvements and impact of the reduced oil price create uncertainty as to the timing of some of our opportunities. We believe that Primoris has the financial and operational strength to meet these short-term challenges, and we continue to be optimistic about longer-term opportunities. Specifically, our view of the outlook for our major end markets currently is as follows:
· Construction of petroleum, natural gas, and natural gas liquid pipelines We expect that at the current oil price, activities in most if not all of the shale basins will be reduced or eliminated significantly reducing any upstream work such as gathering lines and petroleum transport pipelines for the near future. If production from the shale formations continues to increase in the near future, the current disconnect between production and processing locations provides opportunities for our underground construction operations serving midstream companies, primarily Rockford, ARB Underground and Primoris Pipeline & Maintenance groups. We expect that the efforts by gas utilities to move shale gas from the Marcellus region to Florida and other Atlantic states will continue and will provide significant opportunity for Rockford over the next 2-3 years.
· Inspection, maintenance and replacement of gas utility infrastructure We expect that continuing safety enhancements to the gas utility infrastructure will provide continuing opportunities for our ARB Underground operations, especially in California, as well as Q3C in the Midwest. We also expect that ongoing gas utility repair and maintenance opportunities will continue to grow benefiting our Q3C and PES groups.
· Construction of natural gas-fired power plants and heavy industrial plants We expect continued construction opportunities for both base-load and peak shaving power plants; however, we are aware that concerns expressed in California that power plants are not acceptable for environmental reasons may impact the timing of near term construction opportunities. We believe that based on continuing population growth, the intermittency of renewable power resources and the environmental requirements associated with using ocean water for cooling, power plants will be needed in spite of vocal opposition to non-green sources. In addition, the current low price of natural gas could result in the conversion of coal-fired power plants and conversion and expansion at chemical plants and industrial facilities in other parts of the United States. These opportunities would benefit our ARB Industrial group and PES Industrial group.
· Construction of alternative energy facilities, wind farms, solar energy We anticipate continued construction opportunities as state governments remain committed to renewable power standards, primarily benefitting ARB Industrial and to a lesser degree our PES group.
· Transportation infrastructure construction opportunities We believe that passing of longer term highway funding by the federal government in 2015 and voter approval of a highway funding proposition 7 in Texas will provide increased opportunity for our heavy civil and highway groups especially in Texas. We expect that opportunities in the Louisiana market may improve but will remain at depressed levels except for specific programs. This market primarily impacts the operations of JCG.
· Liquefied Natural Gas FacilitiesWe believe the LNG on-purpose opportunities for rail, barge, and other transportation needs will continue to grow, albeit at a slow pace. This market will primarily impact our OnQuest and PES groups. We further believe the existing large scale LNG export facilities currently being planned will require services that will benefit our PES and JCG groups for field services.
Please note that our 2016 outlook and 2016 financial results could be adversely impacted by many factors including those discussed in Item 1A Risk Factors in this Annual Report on Form 10-K. This 2016 Outlook consists of forward-looking statements and should be read in conjunction with the cautions about forward looking statements found at the beginning of this Annual Report on Form 10-K.
Backlog
For companies in the construction industry, backlog can be an indicator of future revenue streams. Different companies define and calculate backlog in different manners. We define backlog is defined as a combination of: (1) anticipated revenue from the uncompleted portions of existing contracts for which we have known revenue amounts for fixed price and fixed unit price contracts (Fixed Backlog), and (2) the estimated revenues on MSAs for the next four quarters (MSA Backlog). We normally do not include time-and-equipment, time-and-materials and cost reimbursable plus fee contracts in the calculation of backlog, when their ultimate revenue amount is difficult to estimate in advance.
The two components of backlog, Fixed Backlog and MSA Backlog, are detailed below.
Fixed Backlog
Fixed Backlog by operating segment and the changes in Fixed Backlog for the periods ending December 31, 2015, 2014 and 2013 were as follows, in millions:
Segment |
|
Beginning Fixed |
|
Contract |
|
Revenue |
|
Ending Fixed |
|
Revenue |
|
Total Revenue |
| ||||||
|
|
|
|
|
|
|
|
|
|
|
|
|
| ||||||
West |
|
$ |
237.3 |
|
$ |
751.2 |
|
$ |
411.4 |
|
$ |
577.1 |
|
$ |
502.2 |
|
$ |
913.6 |
|
East |
|
1,009.7 |
|
342.7 |
|
600.1 |
|
752.3 |
|
12.1 |
|
612.2 |
| ||||||
Energy |
|
301.0 |
|
232.0 |
|
345.2 |
|
187.8 |
|
58.4 |
|
403.6 |
| ||||||
Total |
|
$ |
1,548.0 |
|
$ |
1,325.9 |
|
$ |
1,356.7 |
|
$ |
1,517.2 |
|
$ |
572.7 |
|
$ |
1,929.4 |
|
Segment |
|
Beginning Fixed |
|
Contract |
|
Revenue |
|
Ending Fixed |
|
Revenue |
|
Total Revenue |
| ||||||
|
|
|
|
|
|
|
|
|
|
|
|
|
| ||||||
West |
|
$ |
224.6 |
|
$ |
576.7 |
|
$ |
564.0 |
|
$ |
237.3 |
|
$ |
400.1 |
|
$ |
964.1 |
|
East |
|
1,017.7 |
|
468.8 |
|
476.8 |
|
1,009.7 |
|
13.1 |
|
489.9 |
| ||||||
Energy |
|
240.7 |
|
594.7 |
|
534.4 |
|
301.0 |
|
97.8 |
|
632.2 |
| ||||||
Total |
|
$ |
1,483.0 |
|
$ |
1,640.2 |
|
$ |
1,575.2 |
|
$ |
1,548.0 |
|
$ |
511.0 |
|
$ |
2,086.2 |
|
Segment |
|
Beginning Fixed |
|
Contract |
|
Revenue |
|
Ending Fixed |
|
Revenue |
|
Total Revenue |
| ||||||
|
|
|
|
|
|
|
|
|
|
|
|
|
| ||||||
West |
|
$ |
361.3 |
|
$ |
622.4 |
|
$ |
759.1 |
|
$ |
224.6 |
|
$ |
392.2 |
|
$ |
1,151.4 |
|
East |
|
888.8 |
|
531.6 |
|
402.7 |
|
1,017.7 |
|
27.7 |
|
430.4 |
| ||||||
Energy |
|
96.1 |
|
437.3 |
|
292.8 |
|
240.7 |
|
69.6 |
|
362.4 |
| ||||||
Total |
|
$ |
1,346.2 |
|
$ |
1,591.3 |
|
$ |
1,454.6 |
|
$ |
1,483.0 |
|
$ |
489.6 |
|
$ |
1,944.2 |
|
Revenues recognized from non-Fixed Backlog projects shown above are generated by MSA projects and projects completed under time-and-equipment, time-and-materials and cost-reimbursable-plus-fee contracts.
At December 31, 2015, our total Fixed Backlog was $1.52 billion, representing a decrease of $30.8 million, or 2.0%, from $1.55 billion as of December 31, 2014.
MSA Backlog
The following table outlines historical MSA revenues for the twelve months ending December 31, 2015, 2014 and 2013 ($ in millions):
Year: |
|
MSA Revenues |
|
2013 |
|
462.6 |
|
2014 |
|
502.0 |
|
2015 |
|
565.1 |
|
MSA Backlog includes anticipated MSA revenues for the next twelve months. We determined estimated MSA revenues based on historical trends, anticipated seasonal impacts and estimates of customer demand based on communications with our customers.
Total Backlog
The following table shows the makeup of total backlog, both Fixed Backlog and MSA Backlog, by operating segment at December 31, 2015 (in millions).
Segment: |
|
Fixed Backlog at |
|
MSA Backlog |
|
Total Backlog |
| |||
|
|
|
|
|
|
|
| |||
West |
|
$ |
577.1 |
|
$ |
500.2 |
|
$ |
1,077.3 |
|
East |
|
752.3 |
|
4.0 |
|
756.3 |
| |||
Energy |
|
187.8 |
|
66.5 |
|
254.3 |
| |||
Total |
|
$ |
1,517.2 |
|
$ |
570.7 |
|
$ |
2,087.9 |
|
We expect that during 2016, we wi